[Federal Register Volume 70, Number 24 (Monday, February 7, 2005)]
[Rules and Regulations]
[Pages 6506-6542]
From the Federal Register Online via the Government Publishing Office [www.gpo.gov]
[FR Doc No: 05-1506]



[[Page 6505]]

-----------------------------------------------------------------------

Part II





Department of Transportation





-----------------------------------------------------------------------



48 CFR Chapter 12



Re-issuance of the Department of Transportation Acquisition Regulation; 
Interim Final Rule

Federal Register / Vol. 70, No. 24 / Monday, February 7, 2005 / Rules 
and Regulations

[[Page 6506]]


-----------------------------------------------------------------------

DEPARTMENT OF TRANSPORTATION

Office of the Secretary

48 CFR Chapter 12

[Docket No. OST-2004-19899]
RIN 2105-AD28


Re-issuance of the Department of Transportation Acquisition 
Regulation

AGENCY: Office of the Secretary, DOT.

ACTION: Interim final rule with request for comments.

-----------------------------------------------------------------------

SUMMARY: The Department of Transportation is reissuing the 
Transportation Acquisition Regulation (TAR). This interim final rule 
reflects changes made to implement and/or supplement the Federal 
Acquisition Regulation (FAR). The TAR has been substantially revised to 
update references to obsolete policies, procedures and organizations; 
incorporate electronic links to references such as provisions to the 
FAR, U.S. Codes, the Code of Federal Regulations; and adopt by 
reference Office of Federal Procurement Policy Letters and Executive 
orders. The reissued TAR eliminates coverage that is unnecessary or 
duplicates the FAR or other directives. Only coverage that is suitable 
and necessary will be retained in the regulation. These efforts will 
create a 2004 edition of the TAR that is consistent with the 2001 
edition of the FAR. The 2004 edition of the TAR will replace the 1994 
edition.

DATES: This rule is effective April 8, 2005. Comments should be 
received by March 9, 2005. Late-filed comments will be considered to 
the extent practicable.

ADDRESSES: Comments on this interim final rule should be filed with: 
the Docket Management System, U.S. Department of Transportation, Room 
PL-401, 400 Seventh Street, SW., Washington, DC 20590-0001. Please 
identify the docket number OST-2004-19899 at the beginning of your 
comments. You may also submit comments through the internet to http://dms.dot.gov. You may review the public docket containing comments to 
these proposed regulations in person in the Dockets Office between 9 
a.m. and 5 p.m., Monday through Friday, except Federal holidays. The 
Dockets Office is on the plaza level of the NASSIF Building at the 
Department of Transportation at the above address. Also, you may review 
comments to the docket on the Internet at http://dms.dot.gov. Search by 
using the last set of digits in the docket number (omitting the ``OST-
2004'').

FOR FURTHER INFORMATION CONTACT: Rita Williams, Office of the Senior 
Procurement Executive, M-60, 400 Seventh Street SW., Washington, DC 
20590, (202) 366-9956.

SUPPLEMENTARY INFORMATION:

A. Background

    The Department of Transportation (DOT) has determined that changes 
to the Transportation Acquisition Regulation (TAR) are necessary to 
implement and align it with the 2001 Federal Acquisition Regulation 
(FAR). DOT conducted a comprehensive review of the 1994 Edition of the 
TAR with the goal of updating obsolete coverage, and implementing new 
internal policies applicable to the DOT acquisition workforce. As a 
result, the TAR Re-write team under the direction of the Senior 
Procurement Executive, has undertaken a complete re-write of the TAR.
    The TAR re-write project was conducted in coordination with all 
Operating Administrations (OAS) of the DOT. OAs participated in the 
development of the new TAR language and devised processes that were 
most efficient and least burdensome to its users.
    All United States Coast Guard (USCG) specific language and 
subsequent clauses were removed from the TAR as a result of the 
transfer of USCG from the DOT to the Department of Homeland Security on 
March 1, 2003. As a result of organizational restructuring within DOT, 
the Federal Motor Carrier Safety Administration (FMSCA) was established 
as an OA and given an appropriate agency code for the purpose of 
assigning contract numbers. The delegations of authority and 
responsibilities for internal acquisition functions have been 
authorized at the lowest reasonable level or allowed by higher level 
regulations or statutes. During the re-write of TAR, care was taken to 
eliminate unnecessary coverage including clauses, forms and obsolete 
DOT notices or orders that no longer exist, and restructured language 
that was misaligned with the FAR coverage. The goal of re-writing the 
TAR was to ensure the regulation would only contain current and 
appropriate coverage for a Department level acquisition regulation, and 
to remove and re-designate any internal agency guidance from the TAR to 
the Transportation Acquisition Manual (TAM). To implement Executive 
Order 13043, the Seat Belt Use Policies and Programs clause was 
established. In addition, implementation of the Federal Information 
Security Management Act of 2002 and the Computer Security Act of 1987 
required the establishment of the Requirements for Unclassified 
Information Technology Resources and revision of the Qualification of 
Contractor Employees clauses respectively.
    Those parts which contain no coverage, and have been reserved are: 
Parts 1208, 1209, 1210, 1212, 1218, 1220, 1221, 1225, 1226, 1229, 1230, 
1234, 1238, 1240, 1241, 1243, 1244, and 1248 through 1251.

B. Regulatory Analysis and Notices

    The Department has determined that this rule is not a significant 
regulatory action, and therefore, was not subject to review under 
Executive Order 12866 or under the Department's Regulatory Policies and 
Procedures. The Department does not believe that there would be 
significant federalism implications to warrant the preparation of a 
federalism assessment.

C. Regulatory Flexibility Act

    The Department certifies that this final rule does not have a 
significant economic impact on a substantial number of small entities 
within the meaning of the Regulatory Flexibility Act, 5 U.S.C. 601, et 
seq., because the rule merely restates previous TAR coverage, deletes 
certification requirements which do not significantly alter the amount 
of information currently required, and makes various editorial 
revisions.
    This proposed rule is not expected to have a significant impact on 
a substantial number of small entities because any additional costs 
associated with the rule can be factored into the contract price and 
there is no distinction on this issue between a large or small 
business. Therefore, an Initial Regulatory Flexibility Analysis has not 
been performed. Comments are solicited from small businesses and other 
interested parties and will be considered in accordance with section 
610 of the Act in the development of the final rule.

D. Paperwork Reduction Act

    The information collection requirements associated with this rule 
have been submitted to the Office of Management and Budget (OMB) for 
approval in accordance with 44 U.S.C. chapter 35 under OMB No. 2105-
0517; Administration: Office of the Secretary of Transportation;
    Title: Transportation Acquisition Regulation (TAR);
    Summary: This proposal implements requirements of the Federal 
Acquisition Regulation (FAR), other regulations and

[[Page 6507]]

statutes to solicit, negotiate, award, and administer contracts;
    Use of Information: This information supports the needs of the 
Department of Transportation to evaluate offers, to ensure appropriate 
contract controls are in place, and to minimize conditions conducive to 
fraud, waste, and abuse.
    Burden Estimate: 2,514 hours; Forms: DOT Form 1681 and DOT Form 
4220.43; clauses: 1252.217-76, 1252.237-70 and 73, 1252.242-70 and 72, 
and 1252.245-70.
    Respondents (including number of): The likely respondents to this 
proposed information are contractors and offerors who will respond to 
solicitations or are awarded DOT contracts.
    Frequency: Reports are submitted at different times depending upon 
the need or requirements stipulated in the FAR or TAR.
    Average burden hours per respondent: 7 hours 45 minutes. Comments 
on the proposed information collection requirement should be sent to 
the DOT rulemaking.
    The agency is soliciting comments to--
    (1) evaluate whether the proposed information requirements are 
necessary;
    (2) evaluate the accuracy of the Agency's estimate of the burden;
    (3) enhance the quality, utility, and clarity of the information to 
be collected; and
    (4) minimize the burden of the collection of information on those 
who are to respond, including through the use of appropriate automated, 
electronic, mechanical, or other technological collection techniques or 
other forms of information technology.
    Individuals and organizations may submit comments on the 
information collection requirement by directing them to the address 
listed in the ADDRESSES section of the document. Comments may also be 
submitted to the Office of Information and Regulatory Affairs, OMB, New 
Executive Building, Room 10202, 725 17th Street, NW., Washington, DC 
20053. Attention: Desk Officer for the Department of Transportation.

E. Justification for Interim Final Rule

    This rulemaking pertains exclusively to procedures concerning 
public contracts. Consequently, the requirements of the Administrative 
Procedure Act for notice and an opportunity for public comment prior to 
issuing a final rule do not apply. Under 5 U.S.C. Sec.  553(a)(2), 
matters relating to, among other things, public contracts are not 
subject to notice and comment requirements. For this reason, the 
Department has not issued a notice of proposed rulemaking for this 
final rule. However, consistent with the Department's Regulatory 
Policies and Procedures, the Department is providing an opportunity for 
public comment before the final rule goes into effect.

List of Subjects in 48 CFR Chapter 12

    Government procurement.

    This rule is issued this 13th day of January, 2005, at 
Washington, DC, under the delegated authority of the Senior 
Procurement Executive pursuant to 49 CFR 1.59a (a)(1).
David J. Litman,
Senior Procurement Executive.


0
For the reasons set out in the preamble, 48 CFR chapter 12 is revised 
to read as follows:

CHAPTER 12--DEPARTMENT OF TRANSPORTATION

SUBCHAPTER A--GENERAL

Part

1201 Federal Acquisition Regulation System
1202 Definitions of words and terms
1203 Improper business practices and personal conflicts of interest
1204 Administrative matters

SUBCHAPTER B--ACQUISITION PLANNING

1205 Publicizing contract actions
1206 Competition requirements
1207 Acquisition planning
1208 [Reserved]
1209 [Reserved]
1210 [Reserved]
1211 Describing agency needs
1212 [Reserved]

SUBCHAPTER C--CONTRACTING METHODS AND CONTRACT TYPES

1213 Simplified acquisition procedures
1214 Sealed bidding
1215 Contracting by negotiation
1216 Types of contracts
1217 Special contracting methods
1218 [Reserved]

SUBCHAPTER D--SOCIOECONOMIC PROGRAMS

1219 Small business programs
1220 [Reserved]
1221 [Reserved]
1222 Application of labor laws to government acquisitions
1223 Environment, energy and water efficiency, renewable energy 
technologies, occupational safety, and drug-free workplace
1224 Protection of privacy and freedom of information
1225 [Reserved]
1226 [Reserved]

SUBCHAPTER E--GENERAL CONTRACTING REQUIREMENTS

1227 Patents, data and copyrights
1228 Bonds and insurance
1229 [Reserved]
1230 [Reserved]
1231 Contract cost principles and procedures
1232 Contract financing
1233 Protests, disputes and appeals

SUBCHAPTER F--SPECIAL CATEGORIES OF CONTRACTING

1234 [Reserved]
1235 Research and development contracting
1236 Construction and architect-engineer contracts
1237 Service contracting
1238 [Reserved]
1239 Acquisition of information technology
1240 [Reserved]
1241 [Reserved]

SUBCHAPTER G--CONTRACT MANAGEMENT

1242 Contract administration and audit services
1243 [Reserved]
1244 [Reserved]
1245 Government property
1246 Quality assurance
1247 Transportation
1248 [Reserved]
1249 [Reserved]
1250 [Reserved]
1251 [Reserved]

SUBCHAPTER H--CLAUSES AND FORMS

1252 Solicitations provisions and contract clauses
1253 Forms

PART 1201--FEDERAL ACQUISITION REGULATIONS SYSTEM

Subpart 1201.1--Purpose, Authority, Issuance
Sec.
1201.101 Purpose.
1201.104 Applicability.
1201.105 Issuance.
1201.105-1 Publication and code arrangement.
1201.105-2 Arrangement of regulations.
1201.105-3 Copies.
1201.106 OMB Approval under the Paperwork Reduction Act.

Subpart 1201.2--Administration

1201.201 Maintenance of the FAR.
1201.201-1 The two councils.

Subpart 1201.3--Agency Acquisition Regulations

1201.301 Policy.
1201.301-70 Amendment of (TAR) 48 CFR Chapter 12.
1201.301-71 Effective date.
1201.301-72 TAC or TN numbering.
1201.304 Agency control and compliance procedures.

Subpart 1201.4-70--Deviations From the FAR and TAR

1201.403 Individual deviations. 1201.105
1201.404 Class deviations.

[[Page 6508]]

Subpart 1201.6--Career Development, Contracting Authority and 
Responsibilities

1201.602-3 Ratification of unauthorized commitments.
1201.603-1 General.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.
    Appendix to Part 1252-TAR Matrix

Subpart 1201.1--Purpose, Authority, Issuance


1201.101  Purpose.

    The Department of Transportation (DOT) Acquisition Regulation (TAR) 
establishes uniform acquisition policies and procedures, which 
implement and supplement the Federal Acquisition Regulation (FAR).


1201.104  Applicability.

    (a) Statute, the (FAR) Title 48, Code of Federal Regulations (CFR) 
chapter 1, and (TAR) 48 CFR chapter 12 apply to all acquisitions within 
the Department unless otherwise excluded by statute, the (FAR) 48 CFR 
chapter 1, or (TAR) 48 CFR chapter 12.
    (b) The following order of precedence applies to resolve any 
question of applicability concerning an acquisition regulation or a 
procedure found within (TAR) 48 CFR chapter 12 or the Transportation 
Acquisition Manual (TAM):
    (1) Statute;
    (2) (FAR) 48 CFR chapter 1 or other applicable regulation;
    (3) (TAR) 48 CFR chapter 12;
    (4) DOT Orders; and
    (5) TAM.
    (c) The Maritime Administration may depart from the requirements of 
the (FAR) 48 CFR chapter 1 and (TAR) 48 CFR chapter 12 as authorized by 
40 U.S.C. 113(e)(15) but shall adhere to those regulations to the 
maximum extent practicable. Exceptions from the requirements of the 
(FAR) 48 CFR chapter 1 and/or (TAR) 48 CFR chapter 12 shall be 
documented according to Maritime Administration procedures or in each 
contract file, as appropriate.
    (d) The (FAR) 48 CFR chapter 1, (TAR) 48 CFR chapter 12 and TAM do 
not apply to the Federal Aviation Administration as provided by the 
Department of Transportation and Related Agencies Appropriations Act, 
1996, Public Law 104-50, unless otherwise directed by the Office of the 
Secretary of Transportation.


1201.105  Issuance.


1201.105-1  Publication and code arrangement.

    (a) The (TAR) 48 CFR chapter 12 is published in:
    (1) The Federal Register; and
    (2) Cumulative form in the CFR.
    (b) The TAR is issued as chapter 12 of Title 48 of the CFR.


1201.105-2  Arrangement of regulations.

    (a) General. The (TAR) 48 CFR chapter 12, which encompasses both 
Department and Operating Administration (OA)-specific guidance (see 
(TAR) 48 CFR 1201.3), conforms with the arrangement and numbering 
system prescribed by (FAR) 48 CFR 1.104. Guidance that is OA-specific 
contains the OA's acronym directly after the heading. The following 
acronyms apply:

FHWA--Federal Highway Administration
FMCSA--Federal Motor Carrier Safety Administration
FRA--Federal Railroad Administration
FTA--Federal Transit Administration
MARAD--Maritime Administration
NHTSA--National Highway Traffic Safety Administration
OST--Office of the Secretary
RSPA--Research and Special Programs Administration
SLSDC--Saint Lawrence Seaway Development Corporation

    (b) Numbering. (1) Departmentwide guidance. (i) The numbering 
illustrations at (FAR) 48 CFR 1.105-2 apply to (TAR) 48 CFR chapter 12.
    (ii) Coverage within (TAR) 48 CFR chapter 12 is identified by the 
prefix ``12'' followed by the complete (FAR) 48 CFR chapter 1 cite. For 
example, (TAR) 48 CFR 1201.201-1(b)).
    (iii) Coverage in (TAR) 48 CFR chapter 12 that supplements (FAR) 48 
CFR chapter 1 will use part, subpart, section and subsection numbers 
ending in ``70'' through ``89'' (e.g., (TAR) 48 CFR 1201.301-70). A 
series of numbers beginning with ``70'' is used for provisions and 
clauses.
    (iv) Coverage in (TAR) 48 CFR chapter 12, other than that 
identified with a ``70'' or higher number, that implements the (FAR) 48 
CFR chapter 1 uses the identical number sequence and caption of the 
(FAR) 48 CFR chapter 1 segment being implemented, which may be to the 
paragraph level. Paragraph numbers and letters are not always shown 
sequentially, but may be shown by the specific FAR paragraph 
implemented. For example, (TAR) 48 CFR 1201.201-1 contains only 
paragraph (b) because only this paragraph, correlated with FAR, 
implements (TAR) 48 CFR chapter 12.
    (2) Operating Administration-unique guidance. Supplementary 
material for which there is no counterpart in (FAR) 48 CFR chapter 1 or 
(TAR) 48 CFR chapter 12 shall be identified using chapter, part, 
subpart, section, or subsection numbers of ``90'' and higher.
    (c) References and citations. (TAR) 48 CFR chapter 12 may be 
referred to as the Department of Transportation Acquisition Regulation 
or the TAR. Cross reference to the FAR in (TAR) 48 CFR chapter 12 will 
be cited by ``FAR'' followed by the FAR numbered cite, and cross 
reference to the TAM in (TAR) 48 CFR chapter 12 will be cited by 
``TAM'' followed by the TAM numbered cite. References to specific cites 
within (TAR) 48 CFR chapter 12 will be referenced by the numbered cite 
only.


1201.105-3  Copies.

    (a) Copies of the TAR in Federal Register, and CFR form may be 
purchased from the Superintendent of Documents, Government Printing 
Office, Washington, DC 20402. The electronic version of the Federal 
Register may be found at http://www.nara.gov and the CFR at http://www.gpoaccess.gov.
    (b) The (TAR) 48 CFR chapter 12 and Transportation Acquisition 
Circulars (TACs) are available on the Internet at http://www.dot.gov/ost/m60.


1201.106  OMB Approval Under the Paperwork Reduction Act.

    (a) Data collection by regulation. The information collection and 
recordkeeping requirements contained in (TAR) 48 CFR chapter 12 have 
been approved by the Office of Management and Budget (OMB).
    (b) Data collection under proposed contracts. Under the regulations 
implementing the requirements of the Paperwork Reduction Act (5 CFR 
1320), OMB must approve, prior to obligation of funds, proposed 
contracts which require the collection of information from ten or more 
non-Federal persons or entities. Solicitations requiring this level of 
information collection may be released prior to OMB approval provided 
that:
    (1) A statement is included in the solicitation to the effect that 
the contract will not be awarded until OMB approval of the information 
collection requirements of the proposed contract has been obtained; and
    (2) Enough time is permitted to allow receipt of OMB approval prior 
to contract award.

Subpart 1201.2--Administration


1201.201  Maintenance of the FAR.


1201.201-1  The two councils.

    (b) The SPE is responsible for providing a DOT representative to 
the

[[Page 6509]]

Civilian Agency Acquisition Council (CAAC).

Subpart 1201.3--Agency Acquisition Regulations


1201.301  Policy.

    (a)(1) Acquisition regulations. (i) Departmentwide acquisition 
regulations. The Department of Transportation's (DOT's) Senior 
Procurement Executive (SPE) is the individual having authority to issue 
or authorize the issuance of agency regulations that implement or 
supplement the FAR and to include agency-unique policies, etc. that 
govern the contracting process. This authority was re-delegated from 
the Assistant Secretary for Administration.
    (ii) Operating Administration (OA) acquisition regulations. OA 
acquisition regulations, and any changes thereto, shall be reviewed and 
approved by the Senior Procurement Executive (SPE) for insertion into 
the (TAR) 48 CFR chapter 12 as a TAR supplemental regulation before the 
SPE submits the proposed coverage for publication in the Federal 
Register in accordance with (FAR) 48 CFR 1.501. OA regulations may be 
more restrictive or require higher approval levels than those permitted 
by (TAR) 48 CFR chapter 12 unless otherwise specified.
    (2) Acquisition procedures. The SPE is the individual who issues or 
authorizes the issuance of internal agency guidance at any 
organizational level. DOT internal operating procedures are contained 
in the Transportation Acquisition Manual (TAM). OA procedures necessary 
to implement or supplement the (FAR) 48 CFR chapter 1, (TAR) 48 CFR 
chapter 12, or TAM may be issued by the Head of the Contracting Agency 
(HCA), who may delegate this authority to any organizational level 
deemed appropriate. OA procedures may be more restrictive or require 
higher approval levels than those permitted by the TAM unless otherwise 
specified.
    (b) The authority of the agency head under (FAR) 48 CFR 1.301(b) to 
establish procedures to ensure that agency acquisition regulations are 
published for comment in the Federal Register in conformance with the 
procedures in FAR Subpart 1.5 is delegated to the Office of the General 
Counsel, Assistant General Counsel for Regulation and Enforcement (C-
50).


1201.301-70  Amendment of (TAR) 48 CFR chapter 12.

    (a) Changes to the regulation may be the result of recommendations 
from internal DOT personnel, other Government agencies, or the public. 
Changes shall be submitted in the following format to the Office of the 
Senior Procurement Executive (OSPE), 400 7th Street, SW., Washington, 
DC 20590:
    (1) Problem: Succinctly state the problems created by current (TAR) 
48 CFR chapter 12 language and describe the factual or legal reasons 
necessitating regulatory change.
    (2) Recommendation: Identify the recommended change by using the 
current language (if applicable), and crossing out the deleted words 
with a horizontal line. Insert proposed language in brackets. If the 
change is extensive, deleted language may be displayed by forming a box 
with diagonal lines connecting the corners.
    (3) Discussion: Explain why the change is necessary and how it will 
solve the problem. Address any cost or administrative impact on 
Government activities, offerors, and contractors. Provide any other 
information and documents such as statutes, legal decisions, 
regulations, reports, etc., that may be helpful.
    (4) Point of contact: Provide a point of contact who can answer 
questions regarding the recommendation.
    (b) The (TAR) 48 CFR chapter 12 is maintained by the SPE through 
the TAR/TAM change process. This process consists of input from various 
DOT elements including representatives from DOT OAs specifically 
designated to formulate Departmental acquisition policies and 
procedures.
    (1) Transportation Acquisition Circular (TAC). TACs (see (TAR) 48 
CFR 1201.301-72) will be used to amend (TAR) 48 CFR chapter 12.
    (2) TAR Notice (TN). (i) TNs shall be issued when interim guidance 
is necessary and as often as may be necessary, under any of the 
following circumstances:
    (A) To quickly promulgate selected material in a general or 
narrative manner, in advance of a TAC issuance;
    (B) To disseminate other acquisition related information; or
    (C) To issue guidance which may be effective for a period of 1 year 
or less.
    (ii) Each TN will expire by a specific date.


1201.301-71  Effective date.

    Unless otherwise stated, the following applies--
    (a) Statements in TACs or TNs to the effect that the material 
therein is ``effective upon receipt,'' ``upon a specified date,'' or 
that changes set forth in the document are ``to be used upon receipt,'' 
mean that any new or revised provisions, clauses, procedures, or forms 
must be included in solicitations, contracts or modifications issued 
thereafter; and
    (b) Unless expressly directed by statute or regulation, 
solicitations in process or completed negotiations when the TAC or TN 
is received, new information such as forms and clauses, need not be 
included if the chief of the contracting office determines that it 
would not be in the best interest of the Government to include the new 
information.


1201.301-72  TAC or TN numbering.

    TACs and TNs will be numbered consecutively on a fiscal year basis 
beginning with number ``01'' prefixed by the last two digits of the 
fiscal year (e.g., TNs 04-01 and 04-02 indicate the first two TNs 
issued in fiscal year 2004).


1201.304  Agency control and compliance procedures.

    (a) DOT shall control the proliferation of acquisition regulations 
and any revisions thereto (except as noted in paragraph (b) of this 
section) by using an internal (TAR) 48 CFR chapter 12 change process 
that involves input from many DOT elements including OA representatives 
on the Procurement Management Council. The OA member shall represent 
their OA's viewpoint along with Departmentwide considerations in 
reaching a decision on (TAR) 48 CFR chapter 12 changes.
    (b) OA-unique regulations will not be processed through the TAR/TAM 
change process, but shall be reviewed by OA legal counsel and submitted 
to the OSPE for review and approval. (See (TAR) 48 CFR 1252.101 for 
additional instructions pertaining to provisions and clauses.)

Subpart 1201.4-70--Deviations From the FAR and TAR


1201.403  Individual deviations.

    The Head of the Contracting Activity, or designee with a rank that 
is no lower than that of Senior Executive Service (SES) official or 
that of a Flag Officer, may authorize individual deviations (unless 
(FAR) 48 CFR 1.405(e) applies). However, see TAM 1201.403.


1201.404  Class deviations.

    The SPE may grant in writing class deviations from the (FAR) 48 CFR 
chapter 1 and (TAR) 48 CFR chapter 12, unless (FAR) 48 CFR 1.405(e) 
applies.

[[Page 6510]]

Subpart 1201.6--Career Development, Contracting Authority and 
Responsibilities


1201.602-3  Ratification of unauthorized commitments.

    (b) Policy. DOT policy requires that all procurement decisions 
shall be made only by Government officials having authority to carry 
out such acquisitions. Procurement decisions made by other than 
authorized personnel are contrary to Departmental policy and may be 
considered matters of serious misconduct on the part of the employee 
making an unauthorized commitment. Disciplinary action against an 
employee who makes an unauthorized commitment may be considered.


1201.603-1  General.

    Each DOT OA is responsible for appointing its contracting officers.

PART 1202--DEFINITIONS OF WORDS AND TERMS

Subpart 1202.1--Definitions
Sec.
1202.1 Definitions.
Subpart 1202.70--Internet Links
1202.7000 General.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1202.1--Definitions


1202.1  Definitions.

    Agency, Federal agency or Executive agency means the Department of 
Transportation.
    Chief Information Officer means the Director of the Office of the 
Chief Information Officer (CIO) (S-80).
    Chief of the Contracting Office (COCO) means the individual(s) 
responsible for managing the contracting office(s) within an Operating 
Administration.
    Contracting activity includes all the contracting offices within an 
Operating Administration and is the same as the term ``procuring 
activity.''
    Contracting officer (CO) means an individual authorized by virtue 
of their position or by appointment to perform the functions assigned 
by the Federal Acquisition Regulation (FAR), the Transportation 
Acquisition Regulation (TAR) and Transportation Acquisition Manual 
(TAM).
    Department of Transportation means all of the Operating 
Administrations included within the Department of Transportation (DOT).
    Head of the agency or agency head for Departmental procurement 
means the Deputy Secretary except for acquisition actions that, by the 
terms of a statute or delegation, must be done specifically by the 
Secretary of Transportation.
    Head of the Contracting Activity (HCA) means the individual 
responsible for managing the contracting offices within an Operating 
Administration who is a member of the Senior Executive Service or a 
flag officer and is the same as the term ``Head of the Procuring 
Activity.''
    Head of the Operating Administration (HOA) means the individual 
appointed by the President to manage the operating administration.
    Operating Administration (OA) means the following components of 
DOT:
    (1) Federal Aviation Administration (FAA); (FAA is exempt from FAR, 
TAR and TAM pursuant to the Department of Transportation and Related 
Agencies Appropriations Act, 1996, Public Law 104-50;
    (2) Federal Highway Administration (FHWA);
    (3) Federal Motor Carrier Safety Administration (FMCSA);
    (4) Federal Railroad Administration (FRA);
    (5) Federal Transit Administration (FTA);
    (6) Maritime Administration (MARAD);
    (7) National Highway Traffic Safety Administration (NHTSA);
    (8) Office of the Secretary of Transportation (OST);
    (9) Research and Special Programs Administration (RSPA);
    (10) Saint Lawrence Seaway Development Corporation (SLSDC).
    Senior Procurement Executive (SPE) means the Director of the Office 
of the Senior Procurement Executive (M-60).
    Small Business Specialist (SBS) means the individual appointed by 
each HCA to assist the Director, Office of the Small and Disadvantaged 
Business Utilization in carrying out the purpose of the Small Business 
Act.

Subpart 1202.70--Internet Links


1202.7000  General.

    Most documents cited throughout (TAR) 48 CFR chapter 12, can be 
found on the internet. (TAR) 48 CFR chapter 12 will cite the 
corresponding internet address.

PART 1203--IMPROPER BUSINESS PRACTICES AND PERSONAL CONFLICTS OF 
INTEREST

Subpart 1203.1--Safeguards
Sec.
1203.101-3 Agency regulations.
Subpart 1203.2--Contractor Gratuities to Government Personnel
1203.203 Reporting suspected violations of the Gratuities clause.
1203.204 Treatment of violations.
Subpart 1203.3--Reports of Suspected Antitrust Violations
1203.301 General.
1203.303 Reporting suspected antitrust violations.
Subpart 1203.4--Contingent Fees
1203.405 Misrepresentations or violations of the Covenant Against 
Contingent Fees.
Subpart 1203.5--Other Improper Business Practices
1203.502 Subcontractor kickbacks.
1203.502-2 Subcontractor kickbacks.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1203.1--Safeguards


1203.101-3  Agency regulations.

    (b) 5 CFR part 2635, Standards of Ethical Conduct for Employees of 
the Executive Branch, takes precedence over the DOT regulation at 49 
CFR part 99.

Subpart 1203.2--Contractor Gratuities to Government Personnel


1203.203  Reporting suspected violations of the Gratuities clause.

    (a) Suspected violations of the Gratuities clause shall be reported 
to the contracting officer responsible for the acquisition (or the COCO 
if the contracting officer is suspected of the violation). The 
contracting officer (or COCO) shall obtain from the person reporting 
the violation, and any witnesses to the violation, the following 
information:
    (1) The date, time, and place of the suspected violation;
    (2) The name and title (if known) of the individual(s) involved in 
the violation; and
    (3) The details of the violation (e.g., the gratuity offered or 
intended) to obtain a contract or favorable treatment under a contract.
    (b) The person reporting the violation and witnesses (if any) 
should be requested to sign and date the information certifying that 
the information furnished is true and correct.
    (c) The COCO shall report suspected violations to the Office of the 
Inspector General (OIG) (J-1), 400 7th Street, SW., Washington, DC 
20590, with a copy to General Counsel (C-1) and the OA's Chief Counsel.


1203.204  Treatment of violations.

    (a) The HCA is authorized to determine whether a Gratuities clause 
violation has occurred. If the HCA has been personally and 
substantially involved in the procurement,

[[Page 6511]]

Government legal counsel advice should be sought to determine if a 
substitute for the HCA should be designated.
    (b) The COCO shall ensure that the contractor is afforded the 
hearing procedures required by (FAR) 48 CFR 3.204(b). Government legal 
counsel should be consulted regarding the appropriateness of the 
hearing procedures.
    (c) If the HCA determines that the alleged gratuities violation 
occurred during the ``conduct of an agency procurement'' the COCO shall 
consult with Government legal counsel regarding the approach for 
appropriate processing of either the Procurement Integrity Act 
violation and/or the Gratuities violation.

Subpart 1203.3--Reports of Suspected Antitrust Violations


1203.301  General.

    (b) The same procedures contained in (TAR) 48 CFR 1203.203 shall 
also be followed for suspected antitrust violations, except reports of 
suspected antitrust violations shall be coordinated with legal counsel 
for referral to the Department of Justice, if deemed appropriate.


1203.303  Reporting suspected antitrust violations.

    (b) The same procedures contained in (TAR) 48 CFR 1203.203 shall 
also be followed for suspected antitrust violations, except reports of 
suspected antitrust violations shall be coordinated with legal counsel 
for referral to the Department of Justice, if deemed appropriate.

Subpart 1203.4--Contingent Fees


1203.405  Misrepresentations or violations of the Covenant Against 
Contingent Fees.

    (a) and (b)(4) The same procedures contained in (TAR) 48 CFR 
1203.203 shall also be followed for misrepresentation or violations of 
the covenant against contingent fees, except reports of 
misrepresentation or violations of the covenant against contingent fees 
shall be coordinated with legal counsel for referral to the Department 
of Justice, if deemed appropriate.

Subpart 1203.5--Other Improper Business Practices


1203.502  Subcontractor kickbacks.


1203.502-2  Subcontractor kickbacks.

    (g) The same procedures contained in (TAR) 48 CFR 1203.203 shall 
also be followed for subcontractor kickbacks.

PART 1204--ADMINISTRATIVE MATTERS

Subpart 1204.1--Contract Execution
Sec.
1204.103 Contract clause.
Subpart 1204.8--Government Contract Files
1204.804-5 Procedures for closing out contract.
1204.804-570 Supporting closeout documents.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1204.1--Contract Execution


1204.103  Contract clause.

    The contracting officer shall insert the clause at (FAR) 48 CFR 
52.204-1, Approval of Contract, filled in as appropriate, in 
solicitations and contracts when approval to award the resulting 
contract must be obtained from an official at a level above the 
contracting officer.

Subpart 1204.8--Government Contract Files


1204.804-5  Procedures for closing out contract files.


1204.804-570  Supporting closeout documents.

    (a) When applicable (see paragraphs (a)(1) through (4) of this 
section) and prior to contract closeout, the contracting officer shall 
obtain the listed DOT and Department of Defense (DOD) forms from the 
contractor to facilitate contract closeout.
    (1) Form DOT F 4220.4, Contractor's Release, see (FAR) 48 CFR 
52.216-7;
    (2) Form DOT F 4220.45, Contractor's Assignment of Refunds, 
Rebates, Credits and Other Amounts, (FAR) 48 CFR 52.216-7;
    (3) Form DOT F 4220.46, Cumulative Claim and Reconciliation 
Statement, see (FAR) 48 CFR 4.804-5(a)(13); and
    (4) DD Form 882, Report of Inventions and Subcontracts http://www.dior.whs.mil/forms/DD0882.PDF, see (FAR) 48 CFR 52.227-14.
    (b) The forms listed in paragraph (a) of this section are used 
primarily for the closeout of cost-reimbursement, time-and-materials, 
and labor-hour contracts. However, the forms may also be used for 
closeout of other contract types or when necessary to protect the 
Government's interest.

PART 1205--PUBLICIZING CONTRACT ACTIONS

Subpart 1205.1--Dissemination of Information
Sec.
1205.101 Methods of disseminating information.
Subpart 1205.4--Release of Information
1205.402 General public.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1205.1--Dissemination Of Information


1205.101  Methods of disseminating information.

    (b) The DOT Office of Small and Disadvantaged Business Utilization 
(S-40), 400 7th Street, SW., Washington, DC 20590 publishes a 
Procurement Forecast of planned procurements each fiscal year on their 
Web site at: http://osdbuweb.dot.gov/business/procurement/forecast.html.

Subpart 1205.4--Release of Information


1205.402  General public.

    (a) Upon request, DOT will furnish the general public with the 
following information on proposed contracts and contract awards:
    (1) Prior to the opening of sealed bids or the closing date for 
receipt of proposals, the names of firms invited to submit sealed bids 
or proposals;
    (2) Prior to the opening of sealed bids or the closing date for 
receipt of proposals, the names of firms which attended pre-proposal or 
pre-bid conferences, if any;
    (3) After the opening of sealed bids, names of firms which 
submitted bids; and
    (4) After contract award, the names of firms which submitted 
proposals.
    (b) Requests for other specific information shall be processed in 
accordance with the DOT Freedom of Information Act rules and 
regulations ((TAR) 48 CFR 1224.203).

PART 1206--COMPETITION REQUIREMENTS

Subpart 1206.5--Competition Advocates

Sec.
1206.501 Requirement.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1206.5--Competition Advocates


1206.501  Requirement.

    The DOT Senior Competition Advocate (SCA) is the Deputy Assistant 
Secretary for Administration.

PART 1207--ACQUISITION PLANNING

Subpart 1207.3--Contractor Versus Government Performance
Sec.

[[Page 6512]]

1207.302 General.
1207.305 Solicitation provisions and contract clause.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1207.3--Contractor Versus Government Performance


1207.302  General.

    DOT follows OMB Circular A-76, Performance of Commercial 
Activities, and (FAR) 48 CFR 7.3 when cost comparisons between 
Government and contractor performance are conducted.


1207.305  Solicitation provisions and contract clause.

    The contracting officer may insert clause (TAR) 48 CFR 1252.237-73, 
Key Personnel, in solicitations and contracts when the acquisition is 
conducted pursuant to OMB Circular A-76 and meets the clause 
prescription requirements at (TAR) 48 CFR 1237.110(b).

PART 1211--DESCRIBING AGENCY NEEDS

Subpart 1211.1--Selecting and Developing Requirements Documents
Sec.
1211.101 Order of precedence for requirements documents.
Subpart 1211.2--Using and Maintaining Requirements Documents
1211.204-70 Solicitation provisions and contract clauses.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1211.1--Selecting and Developing Requirements Documents


1211.101  Order of precedence for requirements documents.

    Safeguards to ensure safety, security (including sensitive 
information and information technology security) and environmental 
protection shall be included, as applicable, in requirements documents.

Subpart 1211.2--Using and Maintaining Requirements Documents


1211.204-70  Solicitation provisions and contract clauses.

    The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.211-70, Index for Specifications, when an index or table of 
contents may be furnished with the specification.

PART 1213--SIMPLIFIED ACQUISITION PROCEDURES

Subpart 1213.71--Department of Transportation Procedures for Acquiring 
Training Services
Sec.
1213.7100 Applicability.
1213.7101 Solicitation provision and contract clause.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1213.71--Department of Transportation Procedures for 
Acquiring Training Services


1213.7100  Applicability.

    (a) DOT policy at (TAR) 48 CFR 1237.7000 also applies to the 
Standard Form (SF) 182, Request, Authorization, Agreement and 
Certification of Training, which may be used to acquire training 
services; however, the policy does not apply to training services 
acquired by the Government purchase/credit card. The Government 
purchase/credit card can only be used to acquire training services 
valued at $2,500 or less.
    (b) As reflected in (TAR) 48 CFR 1237.7002, this policy does not 
apply to training attended by DOT employees which is scheduled and 
conducted by Government sources of supply, educational institutions, or 
private entities where DOT does not control or sponsor the training. 
Examples of when the policy does and does not apply include:
    (1) When SF 182s are issued for three DOT employees to attend a one 
week course at a university or other private entity, the policy does 
not apply. DOT does not control this course because the university or 
private entity has a contract in place with the training provider and 
DOT is placing an order under an existing contract; and
    (2) When DOT awards a contract to a university or other private 
entity to provide training for DOT and/or other Government personnel, 
the policy applies. DOT controls this course; therefore, no soliciting 
or advertising of private non-Government training while conducting the 
contracted-for training is permitted.


1213.7101  Solicitation provision and contract clause.

    (a) Contracting officers shall insert the provision at (TAR) 48 CFR 
1252.237-71, Certification of Data, in all solicitations and requests 
for quotations, and the clause at (TAR) 48 CFR 1252.237-72, Prohibition 
on Advertising, in solicitations, requests for quotations, and all 
contracts (e.g., purchase orders, SF 182s) for training services when 
the content and/or presentation of the training is controlled by DOT. 
(Notice: The Secretary of Transportation has determined that the 
certification required by (TAR) 48 CFR 1252.237-71 shall be retained in 
accordance with Section 4301(b)(1)(B)(i)(II) of the Federal Acquisition 
Reform Act (Public Law 104-106, 41 U.S.C. 425, note) and DOT Memorandum 
dated July 17, 1996.)
    (b) Contracting officers shall incorporate the successful offeror's 
certified data into any resultant contract(s). Certified data may be 
adopted by reference, if the contracting officer determines it contains 
information sufficient to reliably describe the certified data 
submitted. For example, this type of information includes dated 
material such as resumes and company or personnel qualifications.

PART 1214--SEALED BIDDING

Subpart 1214.3--Submission of Bids
Sec.
1214.302 Bid submission.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1214.3--Submission of Bids


1214.302  Bid submission.

    (b)(1) Contracting officers may permit telegraphic bids to be 
communicated by means of a telephone call from the telegraph office to 
the designated office provided that procedures and controls have been 
established by the COCO for receiving and safeguarding these incoming 
bids.

PART 1215--CONTRACTING BY NEGOTIATION

Subpart 1215.2--Solicitation and Receipt of Proposals and Information
Sec.
1215.207 Handling proposals and information.
Subpart 1215.4--Contract Pricing
1215.404 Proposal analysis.
1215.404-470 Payment of profit or fee.
Subpart 1215.6--Unsolicited Proposals
1215.602 Policy.
1215.603 General.
1215.604 Agency points of contact.
1215.606 Agency procedures.
1215.606-1 Receipt and initial review.
1215.606-2 Evaluation.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1215.2--Solicitation and Receipt of Proposals and 
Information


1215.207  Handling proposals and information.

    (a) Offeror's proposals and information received in response to a

[[Page 6513]]

request for information shall be marked as required by TAM 1203.104-4, 
as applicable.
    (b) Proposals may be released outside the Government whenever it is 
the only means of receiving the most competent technical and/or 
management evaluation available.

Subpart 1215.4--Contract Pricing


1215.404  Proposal analysis.


1215.404-470  Payment of profit or fee.

    The contracting officer shall not pay profit or fee on 
undefinitized contracts or undefinitized contract modifications. Any 
profit or fee earned shall be paid after the contract or modification 
is definitized.

Subpart 1215.6--Unsolicited Proposals


1215.602  Policy.

    DOT's policy encourages submission of new and innovative ideas that 
will support DOT's mission. Through the various Operating 
Administrations (OAs), DOT is responsible for transportation safety 
improvements, international transportation agreements and the 
continuity of transportation services in the public interest.


1215.603  General.

    DOT will accept unsolicited proposals from any entity for review 
and consideration. However, DOT will not pay any costs associated with 
the preparation of these proposals. Proposals that do not meet the 
definition and applicable content and marking requirements of (FAR) 48 
CFR 15.6 will not be considered under any circumstances and will be 
returned to the submitter.


1215.604  Agency points of contact.

    (a) The DOT does not have a centralized location to receive 
unsolicited proposals. The type of effort submitted in the proposal 
determines which DOT OA should receive and evaluate the proposal.
    (b) Unsolicited proposals should be submitted to the responsible OA 
contracting office for appropriate handling. Specific information 
concerning the mission of each DOT OA is available on the worldwide web 
at http://www.dot.gov. Prospective contractors are urged to contact 
these contracting/procurement offices prior to submitting a proposal to 
ensure that the unsolicited proposal reaches the correct contracting 
office for action. This action will reduce unnecessary paperwork and 
wasted time for both the Government and the prospective contractors.


1215.606  Agency procedures.

    (a) The Chief of the Contracting Office is responsible for 
establishing procedures for controlling unsolicited proposals received 
in the contracting office. Within ten working days after receipt of an 
unsolicited proposal, the contracting office shall review the proposal 
and determine whether the proposal meets the content and marking 
requirements of (FAR) 48 CFR 15.6. If the proposal does not meet these 
requirements, it shall be returned to the submitter giving the reasons 
for noncompliance.
    (b) The OA contracting office is the designated point of contact 
for receipt and handling of unsolicited proposals. Persons within DOT 
who receive unsolicited proposals, such as technical personnel, shall 
forward the document to their responsible contracting office.


1215.606-1  Receipt and initial review.

    (a) The agency contact point must make an initial review 
determination within seven calendar days after receiving a proposal.
    (b) If the proposal meets the requirements at (FAR) 48 CFR 15.606-
1(a), the agency contact point must acknowledge receipt within three 
calendar days after making the initial review determination and advise 
the offeror of the general timeframe for completing the evaluation.
    (c) If the proposal does not meet the requirements of (FAR) 48 CFR 
15.606-1(a), the agency contact point must return the proposal within 
three calendar days after making the determination. The agency point of 
contact must inform the offeror, in writing, of the reasons for 
returning the proposal.


1215.606-2  Evaluation.

    (a) Comprehensive evaluations should be completed within sixty 
calendar days after making the initial review determination. If 
additional time is needed, then the agency contact point shall advise 
the offeror accordingly and provide a new evaluation completion date. 
The evaluating office must neither reproduce nor disseminate the 
proposal to other offices without the consent of the contracting office 
from which the proposal was received for evaluation. If additional 
information from the offeror is required by the evaluating office, the 
evaluator must convey this request to the responsible contracting 
office. The evaluator shall not directly contact the proposal 
originator.
    (b) If the evaluator recommends acceptance of the proposal, the 
responsible contracting officer shall ensure compliance with all of the 
requirements of (FAR) 48 CFR 15.607.

PART 1216--TYPES OF CONTRACTS

Subpart 1216.2--Fixed-Price Contracts
Sec.
1216.203 Fixed-price contracts with economic price adjustment.
1216.203-4 Contract clauses.
1216.203-470 Solicitation provision.
Subpart 1216.4--Incentive Contracts
1216.406-70 DOT contract clauses.
Subpart 1216.5--Indefinite-Delivery Contracts
1216.505 Ordering.
Subpart 1216.6--Time-and-Materials, Labor-Hour, and Letter Contracts
1216.603 Letter contracts.
1216.603-4 Contract clauses.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1216.2--Fixed-Price Contracts


1216.203  Fixed-price contracts with economic price adjustment.


1216.203-4  Contract clauses.


1216.203-470  Solicitation provision.

    The contracting officer shall insert the provision at (TAR) 48 CFR 
1252.216-70, Evaluation of Offers Subject to an Economic Price 
Adjustment Clause, in solicitations containing an economic price 
adjustment clause.

Subpart 1216.4--Incentive Contracts


1216.406-70  DOT contract clauses.

    (a) As authorized by (FAR) 48 CFR 16-406(e), the contracting 
officer shall insert the clause at (TAR) 48 CFR 1252.216-71, 
Determination of Award Fee, in all cost-plus-award-fee solicitations 
and contracts.
    (b) The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.216-72, Performance Evaluation Plan, in all cost-plus-award-fee 
solicitations and contracts.
    (c) The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.216-73, Distribution of Award Fee, in all cost-plus-award-fee 
solicitations and contracts.

Subpart 1216.5--Indefinite-Delivery Contracts


1216.505  Ordering.

    (b)(5) Unless otherwise designated by the Head of the Operating 
Administration, the Competition Advocate for the Operating 
Administration (OA) is designated as the OA Task and Delivery Order 
Ombudsman. If any corrective action is needed after reviewing 
complaints from

[[Page 6514]]

contractors on task and delivery order contracts, the OA Ombudsman 
shall provide a written determination of such action to the contracting 
officer. Issues that cannot be resolved within the OA, shall be 
forwarded to the DOT Task and Delivery Order Ombudsman for review and 
resolution. The DOT Task and Delivery Order Ombudsman is located in the 
Office of the Senior Procurement Executive.

Subpart 1216.6--Time-and-Materials, Labor-Hour, and Letter 
Contracts


1216.603  Letter contracts.


1216.603-4  Contract clauses.

    The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.216-74, Settlement of Letter Contract, in all definitized letter 
contracts.

PART 1217--SPECIAL CONTRACTING METHODS

Subpart 1217.70--Fixed Price Contracts for Vessel Repair, Alteration or 
Conversion
Sec.
1217.7000 Definition.
1217.7001 Clauses.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1217.70--Fixed Price Contracts for Vessel Repair, 
Alteration or Conversion


1217.7000  Definition.

    Lay Days means the time allowed to the master of a vessel for 
loading and unloading the same.


1217.7001  Clauses.

    (a) The clause at (TAR) 48 CFR 1252.217-70, Guarantee, shall be 
used where general guarantee provisions are deemed desirable by the 
contracting officer.
    (1) When inspection and acceptance tests will afford full 
protection to the Government in ascertaining conformance to 
specifications and the absence of defects and deficiencies, no 
guarantee clause for that purpose shall be included in the contract.
    (2) The customary guarantee period, to be inserted in the first 
sentence of the clause at (TAR) 48 CFR 1252.217-70, Guarantee, is 60 
days. In certain instances, it may be advisable for the contracting 
officer to include a contract clause for a guarantee period longer than 
60 days. These instances are as follows:
    (i) If, as result of a full inquiry, the contracting officer 
determines that there will be no increased costs as a result of a 
longer guarantee period, the contracting officer may substitute 
guarantee longer than the usual 60 days; or
    (ii) When the contracting officer's inquiry discloses that 
increased costs will result or are expected to result from a longer 
guarantee period, the contracting officer shall submit a letter to the 
Chief of the Contracting Office, requesting approval for use of 
guarantee period in excess of 60 days. The letter must contain 
sufficient facts to justify the use of a longer guarantee period. Upon 
approval, the contracting officer may insert a longer period in the 
first sentence of the clause at (TAR) 48 CFR 1252.217-70, Guarantee.
    (b) The following clauses are required:
    (1) (TAR) 48 CFR 1252.217-71 through (TAR) 48 CFR 1252.217-74; and,
    (2) (TAR) 48 CFR 1252.217-76 through (TAR) 48 CFR 1252.217-80.
    (c) (TAR) 48 CFR 1252.217-75 may be included in sealed bid fixed-
price solicitations and contracts for vessel repair, alteration, or 
conversion which are to be performed within the United States, its 
possessions, or Puerto Rico.
    (d) Unless inappropriate, the clauses set forth in (TAR) 48 CFR 
1252.217-71 through (TAR) 48 CFR 1252.217-74 and (TAR) 48 CFR 1252.217-
76 through (TAR) 48 CFR 1252.217-80 shall be included.
    (e) (TAR) 48 CFR 1252.217- may be included in negotiated 
solicitations and contracts to be performed outside the United States.

PART 1219--SMALL BUSINESS PROGRAMS

Subpart 1219.2--Policies
Sec.
1219.201 General policy.
Subpart 1219.8--Contracting with the Small Business Administration (The 
8(a) Program)
1219.800 General.
1219.811-3 Contract clauses.
1219.812 Contract administration.
Subpart 1219.10--Small Business Competitiveness Demonstration Program
1219.1003 Purpose.
1219.1005 Applicability.
Appendix A to Part 1219--Targeted Industry Categories

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1219.2--Policies


1219.201  General policy.

    (c) The Director, Office of Small and Disadvantaged Business 
Utilization (S-40), is responsible for carrying out the functions and 
duties in sections 8, 15, and 31 of the Small Business Act, as amended. 
(15 U.S.C. 637, 644, and 657.)

Subpart 1219.8--Contracting with the Small Business Administration 
(The 8(a) Program)


1219.800  General.

    (f) The Small Business Administration (SBA) and DOT have entered 
into a Partnership Agreement (PA) authorizing DOT contracting officers 
to enter into direct 8(a) contracts on behalf of SBA.


1219.811-3  Contract clauses.

    (d)(3) When an acquisition is processed pursuant to the DOT/SBA 
Partnership Agreement, the contracting officer shall use the clause at 
(FAR) 48 CFR 52.219-18, Notification of Competition Limited to Eligible 
8(a) Concerns, with its Alternate III, (TAR) 48 CFR 1252.219-72.
    (f) The contracting officer shall insert the clause at 1252.219-71, 
Section 8(a) Direct Awards, in all solicitations and contracts 
processed under the PA. In accordance with the CAAC Letter 98-3, the 
following FAR clauses shall not be used when processing a Direct 8(a) 
award under the MOU: (FAR) 48 CFR 52.219-11, Special 8(a) Contract 
Conditions, (FAR) 48 CFR 52.219-12, Special 8(a) Subcontract 
Conditions, and (FAR) 48 CFR 52.219-17, Section 8(a) Award.


1219.812  Contract administration.

    (d) All direct 8(a) awards made pursuant to the PA are subject to 
15 U.S.C. 637(a) (21). These contracts contain the clause at (TAR) 48 
CFR 1252.219-71, Section 8(a) Direct Award, which requires the 8(a) 
contractor to notify the SBA and the contracting officer when ownership 
of the firm is being transferred.

Subpart 1219.10--Small Business Competitiveness Demonstration 
Program


1219.1003  Purpose.

    (b) Contracting officers shall use the targeted industry categories 
listed at (TAR) 48 CFR 1219.1005(b) to expand small business 
participation in the small business competitive demonstration program.


1219.1005  Applicability.

    (b) Targeted industry categories. DOT's targeted industry 
categories are shown in Appendix A to this part.

                         Appendix A to Part 1219
------------------------------------------------------------------------
                                             FPDS products and service
      Targeted industry categories*                     code
------------------------------------------------------------------------
(1) Engineering Development..............  AT94
(2) Systems Engineering Services (Only)..  R414

[[Page 6515]]

 
(3) Radio/TV Communication Equipment       5820
 (except airborne).
(4) Maintenance, Repair, and Rebuilding    J028/J010
 of engines, turbines, components and
 weapons equipment.
(5) ADP Central Processing Units:
  Analog.................................  7020
  Digital................................  7021
  Hybrid.................................  7022
(6) ADP Support Equipment................  7035
(7) ADP Components.......................  7050
(8) ADP Development Services and ADP       D302/D305
 Teleprocessing and Timesharing Services.
(9) Gas Turbines and Jet Engines,          2840
 Aircraft; and Components.
(10) Radar Equipment (except airborne)     5840/AT31
 and Navigation and Navigational Aids
 (basic research).
------------------------------------------------------------------------
\*\ The industry categories were derived from Federal Procurement Data
  System Product and Service Codes Manual.

PART 1222--APPLICATION OF LABOR LAWS TO GOVERNMENT ACQUISITIONS

Subpart 1222.1--Basic Labor Policies
Sec.
1222.101 Labor relations.
1222.101-70 Admittance of union representatives to DOT 
installations.
1222.101-71 Contract clauses.
Subpart 1222.4--Labor Standards for Contracts Involving Construction
1222.406 Administration and enforcement.
1222.406-9 Withholding from or suspension of contract payments.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1222.1--Basic Labor Policies


1222.101  Labor relations.


1222.101-70  Admittance of union representatives to DOT installations.

    (a) It is DOT policy to admit labor union representatives of 
contractor employees to DOT installations to visit work sites and 
transact labor union business with contractors, their employees, or 
union stewards pursuant to existing union collective bargaining 
agreements. Their presence shall not interfere with the contractor's 
work progress under a DOT contract nor violate the safety or security 
regulations that may be applicable to persons visiting the 
installation. The union representatives will not be permitted to 
conduct meetings, collect union dues, or make speeches concerning union 
matters while visiting a work site.
    (b) Whenever a union representative is denied entry to a work site, 
the person denying entry shall make a written report to the DOT labor 
coordinator, the Office of the General Counsel, Office of Environmental 
Law, Civil Rights and General Law (C-10), within the Office of the 
Secretary of Transportation or corresponding OA labor advisor, within 
two working days after the request for entry is denied. The report 
shall include the reason(s) for the denial, the name of the 
representative denied entry, the union affiliation and number, and the 
name and title of the person that denied the entry.


1222.101-71  Contract clauses.

    (a) When applicable, the contracting officer may insert the clause 
at (TAR) 48 CFR 1252.222-70, Strikes or Picketing Affecting Timely 
Completion of the Contract Work, in solicitations and contracts.
    (b) When applicable the contracting officer may insert the clause 
at (TAR) 48 CFR 1252.222-71, Strikes or Picketing Affecting Access to a 
DOT Facility, in solicitations and contracts.

Subpart 1222.4--Labor Standards for Contracts Involving 
Construction


1222.406  Administration and enforcement.


1222.406-9  Withholding from or suspension of contract payments.

    (c) Disposition of contract payments withheld or suspended. (1) 
Forwarding wage underpayments to the Secretary of the Treasury. The 
contracting officer shall ensure that a completed Form DOT F 4220.7, 
Employee Claim for Wage Restitution, is obtained from each employee 
claiming restitution under the contract. The Comptroller General 
(Claims Division) must receive this form with a completed Standard Form 
(SF) 1093, Schedule of Withholding Under the Davis-Bacon Act or the 
Contract Work Hours and Safety Standards Act, before payment can be 
made to the employee.

PART 1223--ENVIRONMENT, ENERGY AND WATER EFFICIENCY, RENEWABLE 
ENERGY TECHNOLOGIES, OCCUPATIONAL SAFETY, AND DRUG-FREE WORKPLACE

Subpart 1223.3--Hazardous Material Identification and Material Safety 
Data
Sec.
1223.303 Contract clause.
Subpart 1223.70--Safety Requirements for Selected DOT Contracts
1223.7000 Contract clauses.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1223.3--Hazardous Material Identification and Material 
Safety Data


1223.303  Contract clause.

    The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.223-70, Removal or Disposal of Hazardous Substances--Applicable 
Licenses and Permits, in solicitations and contracts involving the 
removal or disposal of hazardous waste material.

Subpart 1223.70--Safety Requirements for Selected DOT Contracts


1223.7000  Contract clauses.

    (a) Where all or part of a contract will be performed on 
Government-owned or leased property, the contracting officer shall 
insert the clause at (TAR) 48 CFR 1252.223-71, Accident and Fire 
Reporting.
    (b) For all solicitations and contracts under which human test 
subjects will be utilized, the contracting officer shall insert the 
clause at (TAR) 48 CFR 1252.223-72, Protection of Human Subjects. Upon 
written request, copies of the applicable National Highway Traffic 
Safety Administration (NHTSA) policies and procedures may be obtained 
from NHTSA's Associate Administrator for Administration (NPO-200), 400 
7th Street, SW., Washington DC 20590.
    (c) Pursuant to Executive Order 13043, Increasing Seat Belt Use in 
the United States, the contracting officer shall insert the clause at 
(TAR) 48 CFR 1252.223-73, Seat Belt Use Policies and Programs in all 
solicitations and contracts, exceeding the simplified acquisition 
threshold.

PART 1224--PROTECTION OF PRIVACY AND FREEDOM OF INFORMATION

Subpart 1224.1--Protection of Individual Privacy
Sec.
1224.102-70 General.
1224.103 Procedures.
Subpart 1224.2--Freedom of Information Act
1224.203 Policy.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1224.1--Protection of Individual Privacy


1224.102-70  General.

    (a) Systems of records to which the Privacy Act applies shall not 
be released except by the Government regardless of whether the 
Government or a contractor acting on behalf of the Government is 
maintaining the records. Examples of systems of records are:

[[Page 6516]]

    (1) Personnel, payroll and background records personal to any 
officer or employee of DOT, or other person, including his or her 
residential address;
    (2) Medical histories and medical records concerning individuals, 
including applications for licenses; and
    (3) Any other detailed record containing information identifiable 
with a particular person.
    (b) Examples of systems of records to which the Privacy Act does 
not apply are:
    (1) Records that are maintained by a contractor on individuals 
employed by the contractor in the process of providing goods and 
services to the Federal government; and
    (2) Records generated on contract students pursuant to their 
attendance (e.g., admission forms, grade reports) when contracting with 
an educational institution. These records must be similar to those 
maintained on other students, must not reveal their identities, and 
must not be commingled with records of other students.


1224.103  Procedures.

    DOT rules and regulations implementing the Privacy Act of 1974 are 
located at 49 CFR part 10.

Subpart 1224.2--Freedom of Information Act


1224.203  Policy.

    DOT rules and regulations implementing the Freedom of Information 
Act (FOIA) and the names and addresses of the OA FOIA offices are 
located in 49 CFR Part 7. Specific contract award information shall be 
requested from the FOIA office of the OA making the contract award.

PART 1227--PATENTS, DATA, AND COPYRIGHTS

Subpart 1227.3--Patent Rights Under Government Contracts
Sec.
1227.304 Procedures.
1227.304-5 Appeals.
1227.305 Administration of patent rights clauses.
1227.305-4 Conveyance of invention rights acquired by the 
Government.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1227.3--Patent Rights Under Government Contracts


1227.304  Procedures.


1227.304-5  Appeals.

    (b) Agency actions listed at (FAR) 48 CFR 27.304-5(a)(1) and (a)(3) 
through (a)(5) may be appealed to the Head of the Contracting Activity 
(HCA). Actions under this section shall be coordinated with the legal 
counsel of the responsible office.
    (1) Actions must be appealed within 30 days of receipt of the 
written statement required by (FAR) 48 CFR 27.304-5(a). The contractor 
must present all pertinent arguments in the appeal along with 
documentary evidence, if any.
    (2) The HCA shall issue a determination within 45 days from the 
date the contractor's appeal is received.
    (c) Appeals of decisions rendered under (FAR) 48 CFR 27.304-5(a)(2) 
are subject to the following requirements:
    (1) Actions must be appealed within 30 days of receipt of the 
written statement required by (FAR) 48 CFR 27.304-5(a). The contractor 
must present all pertinent arguments in the appeal along with 
documentary evidence, if any.
    (2) The HCA may hold an informal hearing if deemed appropriate or 
at the request of the contractor. The informal hearing shall be held 
after all fact-finding is completed.
    (i) If a hearing is held, there shall be a transcribed record of 
the same. A copy of the transcript shall be available to the contractor 
at cost.
    (ii) Transcription of the hearing may be waived by mutual agreement 
of the parties.
    (3) The HCA shall designate an impartial fact-finding official. The 
official conducting the fact-finding shall prepare findings of fact and 
transmit them to the HCA promptly after the conclusion of the fact-
finding proceeding along with a recommended determination.
    (i) A copy of the findings of fact shall be sent to the contractor 
(assignee or exclusive licensee) by registered or certified mail. The 
contractor (assignee or exclusive licensee) and agency representatives 
will be given 30 days to submit written arguments to the HCA; and, upon 
request by the contractor oral arguments will be held before the HCA as 
part of an informal hearing. The HCA will make the final determination 
as to whether the initial agency action was appropriate under the 
relevant laws and procedures (See 1227.304-5(c)(4)).
    (ii) Any portion of the informal hearing that involves testimony or 
evidence shall be closed to the public. Agencies shall not disclose any 
such information obtained in the course of the appeal to persons 
outside the government except when such release is authorized by the 
contractor (assignee or licensee).
    (4) The HCA's final determination shall be based on the findings of 
facts, together with any other information and written or oral 
arguments submitted by the contractor (assignee or exclusive licensee) 
and agency representatives, and any other information in the 
administrative record. The HCA may reject only those facts that have 
been found clearly erroneous and must explicitly state the rejection 
and the basis for the contrary finding. The HCA shall provide the 
contractor (assignee or exclusive licensee) a written determination by 
certified or registered mail no later than 90 days after fact-finding 
is completed or no later than 90 days after oral arguments, whichever 
is later.


1227.305  Administration of patent rights clauses.


1227.305-4  Conveyance of invention rights acquired by the Government.

    Solicitations and contracts that include a patent rights clause 
must provide the contractor the means to report inventions made in the 
course of contract performance and at contract completion. This 
requirement may be fulfilled by requiring the contractor to submit a DD 
Form 882, Report of Inventions and Subcontracts.

PART 1228--BONDS AND INSURANCE

Subpart 1228.1--Bonds and Other Financial Protections
Sec.
1228.106 Administration.
1228.106-1 Bonds and bond-related forms.
1228.106-6 Furnishing of information.
1228.106-70 Execution and administration of bonds.
1228.106-71 Performance and payment bonds for certain contracts.
1228.106-7100 Waiver.
1228.106-7101 Exception.
1228.106-470 Contract clause.
Subpart 1228.3--Insurance
1228.306 Insurance under fixed-price contracts.
1228.306-70 Contracts for lease of aircraft.
1228.307-1 Group insurance plans.
1228.311-1 Contract clause.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1228.1--Bonds and Other Financial Protections


1228.106  Administration.


1228.106-1  Bonds and bond-related forms.

    (b) Standard Form (SF) 25, Performance Bond, prescribed at (FAR) 48 
CFR 28.106-1(b), shall provide coverage for taxes imposed by the United 
States which are collected, deducted, or withheld from wages paid by 
the contractor. Forms other than the SF 25 (e.g., a commercial form) 
shall not

[[Page 6517]]

be used by contractors when a performance bond is required.


1228.106-6  Furnishing of information.

    (b) When furnishing surety information, the inquirer should also be 
informed that:
    (1) Persons believing that they have legal remedies under the 
Miller Act (40 U.S.C. 3131-3134) are cautioned to consult their own 
legal advisor regarding the proper steps to take to obtain remedies.
    (2) On construction contracts exceeding $2,000, if the contracting 
officer is informed (through routine compliance checking, a complaint, 
or a request for information) that a laborer, mechanic, apprentice, 
trainee, watchman, or guard employed by the contractor or subcontractor 
at any tier may have been paid wages less than those required by the 
applicable labor standards provisions of the contract, the contracting 
officer shall promptly initiate an investigation in accordance with 
(FAR) 48 CFR subpart 22.4, irrespective of the employee's rights under 
the Miller Act. When an employee's request for information is involved, 
the contracting officer shall inform the inquirer that such 
investigation will be made. To insure proper payment to such employees, 
this investigation is required pursuant to the provisions of the Davis-
Bacon Act, Contract Work Hours and Safety Standards Act (40 U.S.C. 
3141), and Copeland (Anti-Kickback) Act (41 U.S.C. 51-58).
    (c) When furnishing a copy of a payment bond and contract in 
accordance with (FAR) 48 CFR 28.106-6(b), the requirement for a copy of 
the contract may be satisfied by furnishing a machine-duplicate copy of 
the contractor's first pages which show the contract number and date, 
the contractor's name and signature, the contracting officer's 
signature, and the description of the contract work. The contracting 
officer furnishing the copies shall place the statement ``Certified to 
be a true and correct copy'' followed by his/her signature, title and 
name of the OA. The fee for furnishing the requested certified copies 
shall be determined in accordance with the DOT Freedom of Information 
Act regulation, 49 CFR part 7, (TAR) 48 CFR 1224.203).


1228.106-70  Execution and administration of bonds.

    (a) The contracting officer shall notify the surety within 30 days, 
of the contractor's failure to perform in accordance with the terms of 
the contract.
    (b) When a partnership is a principal on a bond, the names of all 
the members of the firm shall be listed in the bond following the name 
of the firm, and the phrase ``a partnership composed of.'' If a 
principal is a corporation, the state of incorporation must also appear 
on the bond.
    (c) Performance or payment bond(s), other than an annual bond, 
shall not predate the contract to which it pertains.
    (d) Bonds may be filed with the original contract to which they 
apply, or all bonds can be separately maintained and reviewed quarterly 
for validity. If separately maintained, each contract file shall cross-
reference the applicable bonds.


1228.106-71  Performance and payment bonds for certain contracts.


1228.106-7100  Waiver.

    (a) Pursuant to the authority vested in the Secretary of 
Transportation by the Miller Act, the requirements of 40 U.S.C. 3131 et 
seq. are waived, to the extent authorized in 40 U.S.C. 3134(b), with 
respect to contracts for the construction, alteration, or repair of 
vessels when the contract is made under sections 1535 and 1536 of Title 
31, the Merchant Marine Act 1936 (46 App. U.S.C. 1101 et seq.), or the 
Merchant Ship Sales Act of 1946 (50 App. U.S.C. 1735 et seq.), 
regardless of the terms of the contracts as to payment or title.
    (b) The Miller Act's requirement that certain contracts have 
payment bonds in place in order to protect the public, including the 
Government, material, men and laborers is not generally necessary with 
respect to the classes of contracts described under (TAR) 48 CFR 
1228.106-7100(a). Inasmuch as the Government would directly or 
indirectly bear the burden of premiums for performance and payment 
bonds obtained in connection with such contracts, a substantial savings 
can be made by waiving the requirement that they be obtained. However, 
unusual circumstances may arise in which either payment or performance 
bonds, or both, will be advantageous in connection with certain such 
contracts.


1228.106-7101  Exception.

    A performance and payment bond for the contracts described under 
(TAR) 48 CFR 1228.106-7100(a) may be advantageous in view of unusual 
circumstances arising in connection with such contracts. Requests for 
the authority to include the requirement for either a performance or 
payment bond, or both in the contracts described under (TAR) 48 CFR 
1228.106-7100(a) shall be submitted by the contracting officer to the 
HCA, before a solicitation is issued.


1228.106-470  Contract clause.

    The contracting officer must insert the clause at (TAR) 48 CFR 
1252.228-73, Notification of Miller Act Payment Bond Protection, in 
solicitations and contracts when payment bonds are required.

Subpart 1228.3--Insurance


1228.306  Insurance under fixed-price contracts.


1228.306-70  Contracts for lease of aircraft.

    (a) The contracting officer shall insert the clauses at (TAR) 48 
CFR 1252.228-70 through 1252.228-72, unless otherwise indicated by the 
specific instructions for their use, in any contract for the lease of 
aircraft (including aircraft used in out-service flight training).
    (b) The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.228-70, Loss of or Damage to Leased Aircraft, in any contract for 
the lease of aircraft, except in the following circumstances:
    (1) When the hourly rental rate does not exceed $250 and the total 
rental cost for any single transaction is not in excess of $2,500:
    (2) When the cost of hull insurance does not exceed 10 percent of 
the contract rate; or
    (3) When the lessor's insurer does not grant a credit for uninsured 
hours, thereby preventing the lessor from granting the same to the 
Government.
    (c) The contracting officer must insert the clause at (TAR) 48 CFR 
1252.228-71, Fair Market Value of Aircraft, when fair market value of 
the aircraft can be determined.
    (d) 49 U.S.C. 44112, as amended, provides that an aircraft lessor 
under a lease of 30 days or more is not liable for injury or death of 
persons, or damage or loss of property, unless the aircraft is in the 
actual possession or control of the lessor and the damage occurs 
because of
    (1) The aircraft, engine or propeller, or
    (2) The flight of, or an object falling from, the aircraft, engine, 
or propeller. On short-term or intermittent-use leases, however, the 
owner may be liable for damage caused by operation of the aircraft. It 
is usual for the aircraft owner to retain insurance covering this 
liability during the term of such lease. Such insurance can, often for 
little or no increase in premium, be made to cover the Government's 
exposure to liability as well. In order to take advantage of this 
coverage, the Risks and Indemnities clause at (TAR) 48 CFR 1252.228-72

[[Page 6518]]

prescribed in paragraph (d)(1) of this section shall be used.
    (1) The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.228-72, Risk and Indemnities, in any contract for out-service 
flight training or for the lease of aircraft when the Government will 
have exclusive use of the aircraft for a period of less than thirty 
days.
    (2) Any contract for out-service flight training shall include a 
clause in the contract schedule stating substantially that the 
contractor's personnel shall at all times during the course of the 
training be in command of the aircraft and that at no time must other 
personnel be permitted to take command of the aircraft.


1228.307-1  Group insurance plans.

    (a) Prior approval requirements. The contracting officer shall 
instruct the contractor on a contract-by-contract basis on proposed 
purchases of group insurance plans. Legal advice should be sought where 
necessary on the advantages to the Government.


1228.311-1  Contract clause.

    The contracting officer shall insert the clause at (FAR) 48 CFR 
52.228-7, Insurance Liability to Third Persons, as prescribed in FAR 
28.311-1 unless it is waived by an official one level above the 
contracting officer.

PART 1231--CONTRACT COST PRINCIPLES AND PROCEDURES

Subpart 1231.2--Contracts With Commercial Organizations
Sec.
1231.205 Selected costs.
1231.205-32 Precontract costs.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1231.2--Contracts With Commercial Organizations


1231.205  Selected costs.


1231.205-32  Precontract costs.

    (a) The decision to incur precontract costs is that of the 
contractor. No DOT employee can authorize, demand, or require a 
contractor to incur precontract costs. The contracting officer may 
advise the prospective contractor that any costs incurred before 
contract award are at the contractor's sole risk and that if 
negotiations fail to result in a binding contract, payment of these 
costs may not be made by the Government.
    (b) When the contracting officer determines that incurring 
precontract costs was necessary to meet the proposed contract delivery 
schedule of a cost-reimbursement contract, the clause at (TAR) 48 CFR 
1252.231-70, Date of Incurrence of Costs, may be inserted in the 
resultant contract.

PART 1232--CONTRACT FINANCING

Subpart 1232.70--Contract Payments
Sec.
1232.7002 Invoice and voucher review and approval.
Appendix A to Part 1232--Instructions for Completing The SF 1034
Appendix B to Part 1232--Instructions for Completing the SF 1035

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1232.70--Contract Payments


1232.7002  Invoice and voucher review and approval.

    (a) Under fixed-price contracts, the contracting officer shall 
require the contractor to submit an invoice or voucher in order to 
receive payment under the contract. The invoice or voucher may be on a 
form or company letterhead as long as it meets the requirements of the 
Management and Budget (OMB) regulation at 5 CFR part 1315 as 
implemented by (FAR) 48 CFR Subpart 32.9, and the contract.
    (b) Under other than fixed-price contracts, the contracting office 
shall require the contractor to submit the SF 1034, Public Voucher for 
Purchases and Services Other Than Personal, and the SF 1035, Public 
Voucher for Purchases and Services Other Than Personal (Continuation 
Sheet), to request payments. The forms must be completed as required by 
Appendix A to this part, Instructions for Completing the SF 1034, and 
Appendix B to this part, Instructions for Completing the SF 1035.

    Appendix A to Part 1232--Instructions for Completing the SF 1034
   [The SF 1034, Public Voucher for Purchases and Services Other Than
 Personal, shall be completed in accordance with the below instructions.
       The numbered items correspond to the entries on the form.]
------------------------------------------------------------------------
                                            Data to be inserted in the
         Caption on the SF 1034                       block
------------------------------------------------------------------------
1. U.S. Department, Bureau, or           Name and address of the
 establishment and location.              contracting office which
                                          issued the contract.
2. Date voucher prepared...............  Date voucher submitted to the
                                          designated billing office
                                          cited under the contract or
                                          order.
3. Contract No. and date...............  Contract No. and, when
                                          applicable, the Order No. and
                                          date as shown on the award
                                          document.
4. Requisition No. and date............  Leave blank or fill-in in
                                          accordance with the
                                          instructions in the contract.
5. Voucher No..........................  Start with ``1'' and number
                                          consecutively. A separate
                                          series of consecutive numbers
                                          must be used beginning with
                                          ``1'' for each contract number
                                          or order number (when
                                          applicable). Note: Insert the
                                          word ``FINAL'' if this is the
                                          last voucher.
6. Schedule No.; paid by; date invoice   Leave all these blocks blank.
 received; discount terms; payee's
 account No.; shipped from/to; weight;
 government B/L.
7. Payee's name and address............  Name and address of contractor
                                          as it appears on the contract.
                                          If the contract is assigned to
                                          a bank, also show ``CONTRACT
                                          ASSIGNED'' below the name and
                                          address of the contractor.
8. Number and date or order............  Leave blank. (See 3
                                          above.)
9. Date of delivery or service.........  The period for which the
                                          incurred costs are being
                                          claimed (e.g., month and year;
                                          beginning and ending date of
                                          services, etc.).
10. Articles or services...............  Insert the following: ``For
                                          detail, see the total amount
                                          of the claim transferred from
                                          the attached SF 1035, page X
                                          of X.'' One space below this
                                          line, insert the following:
                                          ``COST REIMBURSABLE-
                                          PROVISIONAL PAYMENT.''
11. Quantity; unit price; (cost; per)..  Leave blank.
12. Amount.............................  Insert the total amount claimed
                                          from the last page of the SF
                                          1035.
Payee must NOT use the space below.....  Do NOT write or type below this
                                          line.
------------------------------------------------------------------------


[[Page 6519]]

Appendix B to Part 1232--Instructions for Completing the SF 1035

    The SF 1035, Public Voucher for Purchases and Services Other 
Than Personal (Continuation Sheet), shall be completed in accordance 
with the below instructions.
    1. Use the same basic instructions for the SF 1035 as used for 
the SF 1034. Ensure that the contract and, if applicable, order 
number, are shown on each continuation sheet. Use as many sheets as 
necessary to show the information required by the contract, 
contracting officer, or responsible audit agency; however, if more 
than one sheet of SF 1035 is used, each sheet shall be in numerical 
sequence.
    2. The following items are generally entered below the line with 
Number and Date of Order; Date of Delivery or Service; Articles or 
Services; Quantity; Unit Price; and Amount (but do not necessarily 
tie to these captions).
    3. Description of data to be inserted as it applies to the 
contract or order number.
    a. Show, as applicable, the target or estimated costs, target or 
fixed-fee, and total contract value, as adjusted by any 
modifications to the contract or order. The FAR permits the 
contracting officer to withhold a percentage of fixed fee until a 
reserve is set aside in an amount that is considered necessary to 
protect the Government's interest.
    b. Show the following costs and supporting data (as applicable) 
to the contract or order:
    (1) Direct Labor. List each labor category, rate per labor hour, 
hours worked, and extended total labor dollars per labor category.
    (2) Premium Pay/Overtime. List each labor category, rate per 
labor hour, hours worked, and the extended total labor dollars per 
labor category. Note: Advance written authorization must be received 
from the contracting officer to work overtime or to pay premium 
rates; therefore, identify the contracting officer's written 
authorization to the contractor.
    (3) Fringe Benefits. If fringe benefits are included in the 
overhead pool, no entry is required. If the contract allows for a 
separate fringe benefit pool, cite the formula (rate and base) in 
effect during the time the costs were incurred. If the contract 
allows for billing fringe benefits as a direct expense, show the 
actual fringe benefit costs.
    (4) Materials, Supplies, Equipment. Show those items normally 
treated as direct costs. Expendable items need not be itemized and 
may be grouped into major classifications such as office supplies. 
However, items valued at $5,000 or more must be itemized. See (FAR) 
48 CFR part 45, Government Property, for reporting of property.
    (5) Travel. List the name and title of traveler, place of 
travel, and travel dates. If the travel claim is based on the actual 
costs expended, show the amount for the mode of travel (i.e., 
airline, private auto, taxi, etc.), lodging, meals, and other 
incidental expenses separately, on a daily basis. These actual costs 
must be supported with receipts to substantiate the costs paid. 
Travel costs for consultants must be shown separately and also 
supported.
    (6) Other Direct Costs. Itemize those costs that cannot be 
placed in categories (1) through (5) above. Categorize these costs 
to the extent possible.
    (7) Total Direct Costs. Cite the sum of categories (1) through 
(6) above.
    (8) Overhead. Cite the rate, base, and extended amount.
    (9) G&A Expense. Cite the rate, base, and extended amount.
    (10) Total Costs. Cite the sum of categories (7) through (9) 
above.
    (11) Fee. Cite the rate, base, and extended amount.
    (12) Total Cost and Fee Claimed. Enter this amount on the SF 
1034.

Completion Voucher

    The completion (final) voucher is the last voucher to be 
submitted for incurred, allocable, and allowable costs expended to 
perform the contract or order. This voucher should include all 
contract reserves, allowable cost withholdings, balance of fixed 
fee, etc. However, the amount of the completion voucher when added 
to the total amount previously paid cannot exceed the total amount 
of the contract.

PART 1233--PROTESTS, DISPUTES, AND APPEALS

Subpart 1233.1 Protests
Sec.
1233.103 Protests to the agency.
1233.104 Protests to GAO.
Subpart 1233.2--Disputes and Appeals
1233.211 Contracting officer's decision.
1233.214 Alternative dispute resolution (ADR).

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1233.1--Protests


1233.103  Protests to the agency.

    (c) DOT Operating Administrations (OAs) shall consider the use of 
Alternate Dispute Resolution (ADR) in all agency protest actions.


1233.104  Protests to GAO.

    The protest process at the Government Accountability Office (GAO) 
may include ADR assistance by GAO. The contracting officer shall, with 
advice of counsel, explore the possibility of using ADR for all GAO 
protests.

Subpart 1233.2--Disputes and Appeals


1233.211  Contracting officer's decision.

    For DOT contracts, the Board of Contract Appeals (BCA) referenced 
at (FAR) 48 CFR 33.211 is the Department of Transportation Board of 
Contract Appeals (S-20), 400 7th Street, SW., Washington, DC 20590. The 
DOTBCA Rules of Procedure are contained in 48 CFR chapter 63, part 
6301.


1233.214  Alternative dispute resolution (ADR).

    (c) The Administrative Dispute Resolution Act (ADRA) of 1990, 
Public Law 101-552, as reauthorized by the Administrative Dispute 
Resolution Act (ADRA) of 1996, Public Law 104-320, authorizes and 
encourages agencies to use mediation, conciliation, arbitration, and 
other techniques for the prompt and informal resolution of disputes, 
either before or after appeal, and for other purposes. ADR procedures 
may be used when:
    (1) There is mutual consent by the parties to participate in the 
ADR process (with consent being obtained either before or after an 
issue in controversy has arisen);
    (2) Prior to the submission of a claim; and
    (3) In resolution of a formal claim. Use of ADR shall be 
coordinated with counsel. For all matters filed with the DOTBCA, the 
DOTBCA Alternate Dispute Resolution (ADR) procedures contained in 48 
CFR Chapter 63, Section 6302.30, ADR Methods (Rule 30), will be 
distributed to the parties, if ADR procedures are used.
    (d) Pursuant to the ADRA, DOT has appointed a Dispute Resolution 
Specialist, who is responsible for the operations of the Center for 
Alternative Dispute Resolution, (C-4). The Center may provide an 
internal DOT neutral agreeable to the parties to conduct any of the 
alternative means of dispute resolution set forth in the ADRA, 5 U.S.C. 
571(3) on a non-reimbursable basis for DOT operating administrations 
and their contracting partners. Alternative means of dispute resolution 
include settlement negotiations, conciliation, facilitation, mediation, 
fact finding, mini-trials, and arbitration, or any combination of these 
methods. The Center may also arrange for an external public or private 
neutral at the parties' expense.

PART 1235--RESEARCH AND DEVELOPMENT CONTRACTING

Sec.
1235.003 Policy.
Subpart 1235.70--Research Misconduct
1235.7000 Contract clause.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.


1235.003  Policy.

    (b) Cost sharing. DOT cost sharing policies shall be in accordance 
with (FAR) 48 CFR 16.303, (FAR) 48 CFR 42.707(a), and Operating 
Administration (OA) procedures.

[[Page 6520]]

Subpart 1235.70--Research Misconduct


1235.7000  Contract clause.

    The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.235-70, Research Misconduct, in all solicitations and contracts 
for research and development. For further information, see DOT's 
Implementation Guidance for Executive Office of the President, Office 
of Science and Technology Policy, ``Federal Policy on Research 
Misconduct,'' dated February 2002.

PART 1236--CONSTRUCTION AND ARCHITECT-ENGINEER CONTRACTS

Subpart 1236.5--Contract Clauses
Sec.
1236.570 Special precautions for work at operating airports.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1236.5--Contract Clauses


1236.570  Special precautions for work at operating airports.

    Where any acquisition will require work at an operating airport, 
insert the clause at (TAR) 48 CFR 1252.236-70, Special Precautions for 
Work at Operating Airports, in solicitations and contracts.

PART 1237--SERVICE CONTRACTING

Subpart 1237.1--Service Contracts--General
Sec.
1237.110 Solicitation provisions and contract clauses.
Subpart 1237.70--Department of Transportation Procedures for Acquiring 
Training Services
1237.7000 Policy.
1237.7001 Certification of data.
1237.7002 Applicability.
1237.7003 Solicitation provisions and contract clause.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1237.1--Service Contracts--General


1237.110  Solicitation provisions and contract clauses.

    (a) Contracting officers shall insert the clause at (TAR) 48 CFR 
1252.237-70, Qualifications of Contractor Employees, in all 
solicitations and contracts for supplies and/or services where 
contractor employees will have access to Government facilities, 
sensitive information, including proprietary data and/or resources.
    (b) The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.237-73, Key Personnel, in solicitations and contracts for services 
when the selection for award is substantially based on the offeror's 
possession of special capabilities regarding personnel.

Subpart 1237.70--Department of Transportation Procedures for 
Acquiring Training Services


1237.7000  Policy.

    When training services are provided under contract, DOT policy 
requires that all prospective contractors:
    (a) Certify that the data provided concerning company 
qualifications, background statements, etc., is current, accurate, and 
complete; and
    (b) Agree to not solicit or advertise private, non-Government 
training while conducting a training course.


1237.7001  Certification of data.

    Towards fulfilling DOT's policy at (TAR) 48 CFR 1237.7000(a), 
contracting officers shall request information from prospective 
contractors for certification purposes. The type of information 
requested is dependent upon the criticality of the service and/or any 
unique or essential qualification requirements.


1237.7002  Applicability.

    The policy at (TAR) 48 CFR 1237.7000 applies to all contracts (as 
defined in FAR 2.101) awarded by DOT for training services when DOT 
controls the content and/or presentation of the course. This policy 
does not apply to courses attended by DOT employees that are offered 
and sponsored by Government sources of supply, educational 
institutions, or private entities where DOT does not control the course 
content or presentation. (See (TAR) 48 CFR 1213.7100 for examples.)


1237.7003  Solicitation provisions and contact clause.

    (a) The contracting officer shall insert the provision at (TAR) 48 
CFR 1252.237-71, Certification of Data, in solicitations and the clause 
at (TAR) 48 CFR 1252.237-72, Prohibition on Advertising, in 
solicitations and contracts for training services when the content and/
or presentation of the course is controlled by DOT.
    (b) Contracting officers shall incorporate the successful offeror's 
certified data into any resultant contract(s). Certified data may be 
adopted by reference, if the contracting officer determines it contains 
sufficient descriptive information (i.e., dated material such as 
resumes, company and/or personnel qualifications) to reliably describe 
the certified data submitted.

PART 1239--ACQUISITION OF INFORMATION TECHNOLOGY

Subpart 1239.1--General
Sec.
1239.70 Solicitation provision and contract clause.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1239.1--General


1239.70  Solicitation provision and contract clause.

    The contracting officer shall insert the provision at (TAR) 48 CFR 
1252.239-71, Information Technology Security Plan and Accreditation, 
and the clause at (TAR) 48 CFR 1252.239-70, Security Requirements for 
Unclassified Information Technology Resources, in all solicitations and 
contracts, exceeding the micro-purchase threshold, that include 
information technology services.

PART 1242--CONTRACT ADMINISTRATION AND AUDIT SERVICES

Subpart 1242.70--Contract Administration Clauses
Sec.
1242.7000 Contract clauses.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1242.70--Contract Administration Clauses


1242.7000  Contract clauses.

    (a) The contracting officer may use the clause at (TAR) 48 CFR 
1252.242-70, Dissemination of Information--Educational Institutions, in 
lieu of the clause at (TAR) 48 CFR 1252.242-72, Dissemination of 
Contract Information, in DOT research contracts with educational 
institutions that require the release or coordination of information.
    (b) The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.242-71, Contractor Testimony, in all solicitations and contracts 
issued by National Highway Traffic Safety Administration (NHTSA). Other 
Operating Administrations (OAs) may use the clause as deemed 
appropriate.
    (c) The contracting officer may insert the clause at (TAR) 48 CFR 
1252.242-72, Dissemination of Contract Information, in all DOT 
contracts, except contracts that require the release or coordination of 
information.
    (d) The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.242-73, Contracting Officer's Technical Representative, in 
solicitations and contracts when it is intended that a representative 
will be assigned to the

[[Page 6521]]

contract to perform functions of a technical nature.

PART 1245--GOVERNMENT PROPERTY

Subpart 1245.5--Management of Government Property in the Possession of 
Contractors
Sec.
1245.505 Records and reports of Government property.
1245.505-14 Reports of Government property.
1245.505-70 Contract clauses.
1245.508-2 Reporting results of inventories.
1245.511 Audit of property control system.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1245.5--Management of Government Property in the Possession 
of Contractors


1245.505  Records and reports of Government Property.


1245.505-14  Reports of Government property.

    When Government property is furnished to or acquired by the 
contractor to perform the contract, the contract shall require the 
contractor to submit annual reports (see (FAR) 48 CFR 45.505-14) to the 
contracting officer not later than September 15 of each year. The 
contractor's report shall be submitted on Form DOT F 4220.43, 
Contractor Report of Government Property.


1245.505-70  Contract clauses.

    Contracting officers shall insert the clause at (TAR) 48 CFR 
1252.245-70 in solicitations and contracts when the contract will 
require Government provided or contractor acquired property.


1245.508-2  Reporting results of inventories.

    The inventory report shall also include the following:
    (a) Name and title of the individual(s) that performed the physical 
inventory;
    (b) An itemized, categorized listing of all property capitalized:
    (1) Land and rights therein;
    (2) Other real property;
    (3) Plant equipment;
    (4) Special test equipment; agency peculiar property; and
    (5) Special tooling; and
    (c) An itemized listing of the property lost, damaged, destroyed, 
or stolen, the circumstances surrounding each incident, and the 
resolution of the incident.


1245.511  Audit of property control system.

    (a) The property administrator (or other Government official 
authorized by the contracting officer) shall audit the contractor's 
property control system whenever there are indications that the 
contractor's property control system may be deficient. Examples of 
deficiencies are:
    (1) Failure of the contractor to acknowledge receipt of Government-
furnished property;
    (2) Failure of the contractor to submit the annual property reports 
required by (TAR) 48 CFR 1245.505-14;
    (3) Failure of the contractor to reconcile its physical inventory 
with its property control record; or
    (4) Failure of the contractor to submit a Government property 
listing when requested by the property administrator.
    (b) When it is determined that the contractor's property control 
system is deficient, the property administrator, in coordination with 
the contracting officer, shall discuss the deficiencies with the 
contractor. If the contractor does not take action to correct the 
deficiencies, the contracting officer shall provide the contractor with 
a written notice of the deficiencies and the date all deficiencies must 
be corrected.

PART 1246--QUALITY ASSURANCE

Subpart 1246.1--General
Sec.
1246.101 Definitions.
1246.101-70 Additional definitions.
Subpart 1246.7--Warranties
1246.705 Limitations.
1246.706 Warranty terms and conditions.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1246.1--General


1246.101  Definitions.


1246.101-70  Additional definitions.

    At no additional cost to the Government means at no increase in 
price for firm-fixed-price contracts, at no increase in target or 
ceiling price for fixed price incentive contracts (see (FAR) 48 CFR 
46.707), or at no increase in estimated cost or fee for cost-
reimbursement contracts.
    Defect means any condition or characteristic in any supplies or 
services furnished by the contractor under the contract that is not in 
compliance with the requirements of the contract.
    Major acquisition means an acquisition or project as defined by TAM 
Chapter 1234, Major System Acquisition.
    Performance requirements means the operating capabilities, 
maintenance, and reliability characteristics of a system that are 
determined to be necessary for it to fulfill the requirement for which 
the system is designed.

Subpart 1246.7--Warranties


1246.705  Limitations.

    (a) The following restrictions are applicable to DOT contracts:
    (1) The contractor shall not be required to honor the warranty on 
any property furnished by the Government except for:
    (i) Defects in installation; and
    (ii) Installation or modification in such a manner that invalidates 
a warranty provided by the manufacturer of the property.
    (2) Any warranty obtained shall specifically exclude coverage of 
damage in time of war (combat damage) or national emergency.
    (3) Contracting officers shall not include in a warranty clause any 
terms that require the contractor to incur liability for loss, damage, 
or injury to third parties.
    (b) [Reserved]


1246.706  Warranty terms and conditions.

    (a) When appropriate and cost effective, the contracting officer 
shall comply with the following requirements when developing the 
warranty terms and conditions:
    (1) Identify the affected line item(s) and the applicable 
specification(s);
    (2) Require that the line item's design and manufacture will 
conform to:
    (i) An identified revision of a top-level drawing; and/or
    (ii) An identified specification or revision thereof;
    (3) Require that the line item conform to the specified Government 
performance requirements;
    (4) Require that all line items and components delivered under the 
contract will be free from defects in materials and workmanship;
    (5) State that if the contractor fails to comply with specification 
or there are defects in material and workmanship, the contractor will 
bear the cost of all work necessary to achieve the specified 
performance requirements, including repair and/or replacement of all 
parts;
    (6) Require the timely replacement/repair of warranted items and 
specify lead times for replacement/repair where possible;
    (7) Identify the specific paragraphs containing Government 
performance requirements that the contractor must meet;
    (8) Ensure that any performance requirements identified as goals or 
objectives beyond specification requirements are excluded from the 
warranty provision;
    (9) Specify what constitutes the start of the warranty period 
(e.g., delivery, acceptance, in-service date), the ending

[[Page 6522]]

of the warranty (e.g., passing a test or demonstration, or operation 
without failure for a specified time period), and circumstances 
requiring an extension of warranty duration (e.g., extending the 
warranty period as a result of mass defect correction during warranty 
period);
    (10) Identify what transportation costs will be paid by the 
contractor in relation to the warranty coverage;
    (11) In addition to combat damage, identify any conditions which 
will not be covered by the warranty, and
    (12) Identify any limitation on the total dollar amount of the 
contractor's warranty exposure, or agreement to share costs after a 
certain dollar threshold to avoid unnecessary warranty returns.
    (b) In addition to the terms and conditions listed in paragraph (a) 
of this section, the contracting officer shall consider the following 
when a warranty clause is being used for a major acquisition:
    (1) For line items or components which are commercially available, 
obtaining a warranty as is normally provided by the manufacturer or 
supplier, in accordance with (FAR) 48 CFR 46.703(d) and (FAR) 48 CFR 
46.710(b)(2).
    (2) Obtaining a warranty of compliance with the stated requirements 
for line items or components provided in accordance with either design 
and manufacturing or performance requirements as specified in the 
contract or any modification to that contract.
    (3) The warranty provided under paragraph (b)(2) of this section 
shall provide that in the event the line items or any components 
thereof fails to meet the terms of the warranty provided, the 
contracting officer may:
    (i) Require the contractor to promptly take such corrective action 
as the contracting officer determines to be necessary at no additional 
cost to the Government, including repairing or replacing all parts 
necessary to achieve the requirements set forth in the contract;
    (ii) Require the contractor to pay costs reasonably incurred by the 
United States in taking necessary corrective action; or
    (iii) Equitably reduce the contract price.
    (4) Inserting remedies, exclusions, limitations and durations, 
provided these are consistent with the specific requirements of this 
subpart and (FAR) 48 CFR 46.706.
    (5) Excluding from the terms of the warranty certain defects for 
specified supplies (exclusions) and limiting the contractor's liability 
under the terms of the warranty (limitations), as appropriate, if 
necessary to derive a cost-effective warranty in light of the technical 
risk, contractor financial risk, or other program uncertainties.
    (6) Structuring of a broader and more comprehensive warranty where 
such is advantageous. Likewise, the contracting officer may narrow the 
scope of a warranty when appropriate (e.g., where it would be 
inequitable to require a warranty of all performance requirements 
because a contractor had not designed the system).
    (c) Any contract that contains a warranty clause must contain 
warranty implementation procedures, including warranty notification 
content and procedures, and identify the individuals responsible for 
implementation of warranty provisions. The contract may also permit the 
contractor's participation in investigation of system failures, 
providing that the contractor is reimbursed at established rates for 
fault isolation work, and that the Government receive credit for any 
payments where equipment failure is covered by warranty provisions.

PART 1247--TRANSPORTATION

Subpart 1247.5--Ocean Transportation by U.S.-Flag Vessels
Sec.
1247.506 Procedures.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1247.5--Ocean Transportation by U.S.-Flag Vessels


1247.506  Procedures.

    (a) The Maritime Administration (MARAD) is the enforcing agency of 
the cargo preference statutes. MARAD can assist contractors in locating 
U.S.-flag carriers and determine when such services are not available 
and they can assist contracting officers in evaluating costs, services, 
and other matters regarding ocean transportation.
    (d) If no transportation officer is available, the contracting 
officer shall submit a copy of the rated ``on board'' bill of lading, 
for each shipment, no later than 20 days after the vessel's loading 
date for exports and 30 days for imports as stated in 46 CFR 381.3. All 
non-vessel ocean common carrier bills of lading should be accompanied 
by the underlying carrier's ocean bill of lading. The documents shall 
be sent to the Maritime Administration, Office of Cargo Preference, 
MAR-590, 400 Seventh Street, SW., Washington, DC 20590. The bill of 
lading shall contain the following information:
    (1) Name of sponsoring Government agency or department;
    (2) Name of vessel;
    (3) Vessel flag of registry;
    (4) Date of loading;
    (5) Port of loading;
    (6) Port of final discharge;
    (7) Commodity description;
    (8) Gross weight in kilos;
    (9) Total ocean freight revenue in U.S. dollars.

PART 1252--SOLICITATIONS PROVISIONS AND CONTRACT CLAUSES

Subpart 1252.1--Instructions for Using Provisions and Clauses
Sec.
1252.101 Using Part 1252.
Subpart 1252.2--Text of Provisions and Clauses
1252.211-70 Index for specifications.
1252.216-70 Evaluation of offers subject to an economic price 
adjustment clause.
1252.216-71 Determination of award fee.
1252.216-72 Performance evaluation plan.
1252.216-73 Distribution of award fee.
1252.216-74 Settlement of letter contract.
1252.217-70 Guarantee.
1252.217-71 Delivery and shifting of vessel.
1252.217-72 Performance.
1252.217-73 Inspection and manner of doing work.
1252.217-74 Subcontracts.
1252.217-75 Lay days.
1252.217-76 Liability and insurance.
1252.217-77 Title.
1252.217-78 Discharge of liens.
1252.217-79 Delays.
1252.217-80 Department of Labor Safety and Health Regulations for 
Ship Repairing.
1252.219-71 Section 8(a) Direct Awards.
1252.219-72 Notification of Competition Limited to Eligible 8(a) 
Concerns--Alternate III.
1252.222-70 Strikes or picketing affecting timely completion of the 
contract work.
1252.222-71 Strikes or picketing affecting access to a DOT facility.
1252.223-70 Removal or disposal of hazardous substances--applicable 
licenses and permits.
1252.223-71 Accident and fire reporting.
1252.223-72 Protection of human subjects.
1252.223-73 Seat belt use policies and programs.
1252.228-70 Loss of or damage to leased aircraft.
1252.228-71 Fair market value of aircraft
1252.228-72 Risk and indemnities.
1252.228-73 Notification of Miller Act payment bond protection.
1252.231-70 Date of incurrence of costs.
1252.235-70 Research misconduct.
1252.236-70 Special precautions for work at operating airports.
1252.237-70 Qualifications of contractor employees.
1252.237-71 Certification of data.
1252.237-72 Prohibition on advertising.
1252.237-73 Key personnel.

[[Page 6523]]

1252.239-70 Security requirements for unclassified information 
technology resources.
1252.239-71 Information technology security plan and accreditation.
1252.242-70 Dissemination of information--educational institutions.
1252.242-71 Contractor testimony.
1252.242-72 Dissemination of contract information.
1252.242-73 Contracting officer's technical representative.
1252.245-70 Government property reports.
Appendix to Part 1252--TAR Matrix

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1252.1--Instructions for Using Provisions and Clauses


1252.101  Using Part 1252.

    (b) Numbering.
    (2)(i) Provisions or clauses that supplement the FAR.
    (A) Agency-prescribed provisions and clauses permitted by TAR and 
used on a standard basis (i.e., normally used in two or more 
solicitations or contracts regardless of contract type) shall be 
prescribed and contained in the TAR. Operating Administrations (OAs) 
desiring to use a provision or a clause on a standard basis shall 
submit a request containing a copy of the clause(s), justification for 
its use, and evidence of legal counsel review to the Office of the 
Senior Procurement Executive in accordance with (TAR) 48 CFR 1201.304 
for possible inclusion in the TAR.
    (B) Provisions and clauses used on a one-time basis (i.e., non-
standard provisions and clauses) may be approved by the contracting 
officer, unless a higher level is designated by the OA. This authority 
is permitted subject to:
    (1) Evidence of legal counsel review in the contract file;
    (2) Inserting these clauses in the appropriate sections of the 
uniform contract format; and
    (3) Ensuring the provisions and clauses do not deviate from the 
requirements of the FAR and TAR.

Subpart 1252.2--Text of Provisions and Clauses


1252.211-70  Index for specifications.

    As prescribed in (TAR) 48 CFR 1211.204-70, insert the following 
clause:

Index for Specifications (Apr 2005)

    If an index or table of contents is furnished in connection with 
specifications, such index or table of contents is for convenience 
only. Its accuracy and completeness is not guaranteed, and it is not 
a part of the specification. In case of discrepancy between the 
index or table of contents and the specifications, the 
specifications shall govern.

(End of clause)


1252.216-70  Evaluation of offers subject to an economic price 
adjustment clause.

    As prescribed in (TAR) 48 CFR 1216.203-470, insert the following 
provision:

Evaluation of Offers Subject to an Economic Price Adjustment Clause 
(Oct 1994)

    Offers shall be evaluated without an amount for an economic 
price adjustment being added. Offers will be rejected which: (1) 
Increase the ceiling stipulated; (2) limit the downward adjustment; 
or (3) delete the economic price adjustment clause. If the offer 
stipulates a ceiling lower than that included in the solicitation, 
the lower ceiling will be incorporated into any resulting contract.

(End of provision)


1252.216-71  Determination of award fee.

    As prescribed in (TAR) 48 CFR 1216.406, insert the following 
clause:

Determination of Award Fee (Apr 2005)

    (a) The Government shall evaluate contractor performance at the 
end of each specified evaluation period to determine the amount of 
award. The contractor agrees that the amount of award and the award 
fee methodology are unilateral decisions to be made at the sole 
discretion of the Government.
    (b) Contractor performance shall be evaluated according to a 
Performance Evaluation Plan. The contractor shall be periodically 
informed of the quality of its performance and areas in which 
improvements are expected.
    (c) The contractor shall be promptly advised, in writing, of the 
determination and reasons why the award fee was or was not earned. 
The contractor may submit a performance self-evaluation for each 
evaluation period. The amount of award is at the sole discretion of 
the Government but any self-evaluation received within ------ 
(insert number) days after the end of the current evaluation period 
will be given such consideration, as may be deemed appropriate by 
the Government.
    (d) The amount of award fee which can be awarded in each 
evaluation period is limited to the amounts set forth at (identify 
location of award fee amounts). Award fee which is not earned in an 
evaluation period cannot be reallocated to future evaluation 
periods.

(End of clause)


1252.216-72  Performance evaluation plan.

    As prescribed in (TAR) 48 CFR 1216.406(b), insert the following 
clause:

Performance Evaluation Plan (Oct 1994)

    (a) A Performance Evaluation Plan shall be unilaterally 
established by the Government based on the criteria stated in the 
contract and used for the determination of award fee. This plan 
shall include the criteria used to evaluate each area and the 
percentage of award fee (if any) available for each area. A copy of 
the plan shall be provided to the contractor ------ (insert number) 
calendar days prior to the start of the first evaluation period.
    (b) The criteria contained within the Performance Evaluation 
Plan may relate to: (1) Technical (including schedule) requirements, 
if appropriate; (2) Management; and (3) Cost.
    (c) The Performance Evaluation Plan may, consistent with the 
contract, be revised unilaterally by the Government at any time 
during the period of performance. Notification of such changes shall 
be provided to the contractor ------ (insert number) calendar days 
prior to the start of the evaluation period to which the change will 
apply.

(End of clause)


1252.216-73  Distribution of award fee.

    As prescribed in (TAR) 48 CFR 1216.406(c), insert the following 
clause:

Distribution of Award Fee (Apr 2005)

    (a) The total amount of award fee available under this contract 
is assigned according to the following evaluation periods and 
amounts:
Evaluation Period:
Available Award Fee: (insert appropriate information)

    (b) After the contractor has been paid 85 percent of the base 
fee and potential award fee, the Government may withhold further 
payment of the base fee and award fee until a reserve is set aside 
in an amount that the Government considers necessary to protect its 
interest. This reserve shall not exceed 15 percent of the total base 
fee and potential award fee or $100,000, whichever is less. 
Thereafter, base fee and award fee payments may continue.
    (c) In the event of contract termination, either in whole or in 
part, the amount of award fee available shall represent a prorata 
distribution associated with evaluation period activities or events 
as determined by the Government.
    (d) The Government will promptly make payment of any award fee 
upon the submission by the contractor to the contracting officer's 
authorized representative, of a public voucher or invoice in the 
amount of the total fee earned for the period evaluated. Payment may 
be made without using a contract modification.

(End of clause)


1252.216-74  Settlement of letter contract.

    As prescribed in (TAR) 48 CFR 1216.603-4, insert the following 
clause:

Settlement of Letter Contract (Oct 1994)

    (a) This contract constitutes the definitive contract 
contemplated by issuance of letter contract ------ (insert number) 
dated -------- (insert effective date). It supersedes the letter 
contract and its modification number(s) -------- (insert number(s)) 
and, to the extent of any inconsistencies, governs.
    (b) The cost(s) and fee(s), or price(s), established in this 
definitive contract represents full and complete settlement of 
letter contract (insert number and modification number(s) -------- 
(insert

[[Page 6524]]

number(s)). Payment of the agreed upon fee or profit withheld 
pending definitization of the letter contract, may commence 
immediately at the rate and times stated within this contract.

(End of clause)


1252.217-70  Guarantee.

    As prescribed at (TAR) 48 CFR 1217.7001(a), insert the following 
clause:

Guarantee (Apr 2005)

    (a) In the event any work performed or materials furnished by 
the contractor prove defective or deficient within 60 days from the 
date of redelivery of the vessel(s), the Contractor, as directed by 
the Contracting Officer and at its own expense, shall correct and 
repair the deficiency to the satisfaction of the Contracting 
Officer.
    (b) If the Contractor or any subcontractor has a guarantee for 
work performed or materials furnished that exceeds the 60 day 
period, the Government shall be entitled to rely upon the longer 
guarantee until its expiration.
    (c) With respect to any individual work item identified as 
incomplete at the time of redelivery of the vessel(s), the guarantee 
period shall run from the date the item is completed.
    (d) If practicable, the Government shall give the Contractor an 
opportunity to correct the deficiency.
    (1) If the Contracting Officer determines it is not practicable 
or is otherwise not advisable to return the vessel(s) to the 
Contractor, or the Contractor fails to proceed with the repairs 
promptly, the Contracting Officer may direct that the repairs be 
performed elsewhere, at the Contractor's expense.
    (2) If correction and repairs are performed by other than the 
Contractor, the Contracting Officer may discharge the Contractor's 
liability by making an equitable deduction in the price of the 
contract.
    (e) The Contractor's liability shall extend for an additional 90 
day guarantee period on those defects or deficiencies that the 
Contractor corrected.
    (f) At the option of the Contracting Officer, defects and 
deficiencies may be left uncorrected. In that event, the Contractor 
and Contracting Officer shall negotiate an equitable reduction in 
the contract price. Failure to agree upon an equitable reduction 
shall constitute a dispute under the Disputes clause of this 
contract.

(End of clause)


1252.217-71  Delivery and shifting of vessel.

    As prescribed at (TAR) 48 CFR 1217.7001(b) and (c), insert the 
following clause:

Delivery and Shifting of Vessel (Oct 1994)

    The Government shall deliver the vessel to the Contractor at his 
place of business. Upon completion of the work, the Government shall 
accept delivery of the vessel at the Contractor's place of business. 
The Contractor shall provide, at no additional charge, upon 24 
hours' advance notice, a tug or tugs and docking pilot, acceptable 
to the Contracting Officer, to assist in handling the vessel between 
(to and from) the Contractor's plant and the nearest point in a 
waterway regularly navigated by vessels of equal or greater draft 
and length. While the vessel is in the hands of the Contractor, any 
necessary towage, cartage, or other transportation between ship and 
shop or elsewhere, which may be incident to the work herein 
specified, shall be furnished by the Contractor without additional 
charge to the Government.

(End of clause)


1252.217-72  Performance.

    As prescribed at (TAR) 48 CFR 1217.7001(b) and (c), insert the 
following clause:

Performance (Oct 1994)

    (a) Upon the award of the contract, the Contractor shall 
promptly start the work specified and shall diligently prosecute the 
work to completion. The Contractor shall not start work until the 
contract has been awarded except in the case of emergency work 
ordered by the Contracting Officer in writing.
    (b) The Government shall deliver the vessel described in the 
contract at the time and location specified in the contract. Upon 
completion of the work, the Government shall accept delivery of the 
vessel at the time and location specified in the contract.
    (c) The Contractor shall without charge--
    (1) Make available to personnel of the vessel while in dry dock 
or on a marine railway, sanitary lavatory and similar facilities at 
the plant acceptable to the Contracting Officer;
    (2) Supply and maintain suitable brows and gangways from the 
pier, dry dock, or marine railway to the vessel;
    (3) Treat salvage, scrap or other ship's material of the 
Government resulting from performance of the work as items of 
Government-furnished property, in accordance with the Government 
Property (Fixed Price Contracts) clause;
    (4) Perform, or pay the cost of, any repair, reconditioning or 
replacement made necessary as the result of the use by the 
Contractor of any of the vessel's machinery, equipment or fittings, 
including, but not limited to, winches, pumps, rigging, or pipe 
lines; and
    (5) Furnish suitable offices, office equipment and telephones at 
or near the site of the work for the Government's use.
    (d) The contract will state whether dock and sea trials are 
required to determine whether or not the Contractor has 
satisfactorily performed the work.
    (1) If dock and sea trials are required, the vessel shall be 
under the control of the vessel's commander and crew.
    (2) The Contractor shall not conduct dock and sea trials not 
specified in the contract without advance approval of the 
Contracting Officer. Dock and sea trials not specified in the 
contract shall be at the Contractor's expense and risk.
    (3) The Contractor shall provide and install all fittings and 
appliances necessary for dock and sea trials. The Contractor shall 
be responsible for care, installation, and removal of instruments 
and apparatus furnished by the Government for use in the trials.
(End of clause)


1252.217-73  Inspection and manner of doing work.

    As prescribed at (TAR) 48 CFR 1217.7001(b) and (c), insert the 
following clause:

Inspection and Manner of Doing Work (Oct 1994)

    (a) The Contractor shall perform work in accordance with the 
contract, any drawings and specifications made a part of the job 
order, and any change or modification issued under the Changes 
clause.
    (b)(1) Except as provided in paragraph (b)(2) of this clause, 
and unless otherwise specifically provided in the contract, all 
operational practices of the Contractor and all workmanship, 
material, equipment, and articles used in the performance of work 
under this contract shall be in accordance with the best commercial 
marine practices and the rules and requirements of all appropriate 
regulatory bodies including, but not limited to the American Bureau 
of Shipping, the U.S. Coast Guard, and the Institute of Electrical 
and Electronic Engineers, in effect at the time of Contractor's 
submission of offer, and shall be intended and approved for marine 
use.
    (2) When Navy specifications are specified in the contract, the 
Contractor shall follow Navy standards of material and workmanship. 
The solicitation shall prescribe the Navy standard whenever 
applicable.
    (c) The Government may inspect and test all material and 
workmanship at any time during the Contractor's performance of the 
work.
    (1) If, prior to delivery, the Government finds any material or 
workmanship is defective or not in accordance with the contract, in 
addition to its rights under the Guarantee clause, the Government 
may reject the defective or nonconforming material or workmanship 
and require the Contractor to correct or replace it at the 
Contractor's expense.
    (2) If the Contractor fails to proceed promptly with the 
replacement or correction of the material or workmanship, the 
Government may replace or correct the defective or nonconforming 
material or workmanship and charge the Contractor the excess costs 
incurred.
    (3) As specified in the contract, the Contractor shall provide 
and maintain an inspection system acceptable to the Government.
    (4) The Contractor shall maintain complete records of all 
inspection work and shall make them available to the Government 
during performance of the contract and for 90 days after the 
completion of all work required.
    (d) The Contractor shall not permit any welder to work on a 
vessel unless the welder is, at the time of the work, qualified to 
the standards established by the U.S. Coast Guard, American Bureau 
of Shipping, or Department of the Navy for the type of

[[Page 6525]]

welding being performed. Qualifications of a welder shall be as 
specified in the contract.
    (e) The Contractor shall--
    (1) Exercise reasonable care to protect the vessel from fire;
    (2) Maintain a reasonable system of inspection over activities 
taking place in the vicinity of the vessel's magazines, fuel oil 
tanks, or storerooms containing flammable materials.
    (3) Maintain a reasonable number of hose lines ready for 
immediate use on the vessel at all times while the vessel is berthed 
alongside the Contractor's pier or in dry dock or on a marine 
railway;
    (4) Unless otherwise provided in the contract, provide 
sufficient security patrols to reasonably maintain a fire watch for 
protection of the vessel when it is in the Contractor's custody;
    (5) To the extent necessary, clean, wash, and steam out or 
otherwise make safe, all tanks under alteration or repair.
    (6) Furnish the Contracting Officer a ``gas-free'' or ``safe-
for-hotwork'' certificate before any hot work is done on a tank;
    (7) Treat the contents of any tank as Government property in 
accordance with the Government Property (Fixed-Price Contracts) 
clause; and
    (8) Dispose of the contents of any tank only at the direction, 
or with the concurrence, of the Contracting Officer.
    (9) Be responsible for the proper closing of all openings to the 
vessel's underwater structure upon which work has been performed. 
The contractor additionally must advise the COTR of the status of 
all valves closures and openings for which the contractor's workers 
were responsible.
    (f) Except as otherwise provided in the contract, when the 
vessel is in the custody of the Contractor or in dry dock or on a 
marine railway and the temperature is expected to go as low as 35 
Fahrenheit, the Contractor shall take all necessary steps to--
    (1) Keep all hose pipe lines, fixtures, traps, tanks, and other 
receptacles on the vessel from freezing; and
    (2) Protect the stern tube and propeller hubs from frost damage.
    (g) The Contractor shall, whenever practicable--
    (1) Perform the required work in a manner that will not 
interfere with the berthing and messing of Government personnel 
attached to the vessel; and
    (2) Provide Government personnel attached to the vessel access 
to the vessel at all times.
    (h) Government personnel attached to the vessel shall not 
interfere with the Contractor's work or workers.
    (i)(1) The Government does not guarantee the correctness of the 
dimensions, sizes, and shapes set forth in any contract, sketches, 
drawings, plans, or specifications prepared or furnished by the 
Government, unless the contract requires that the Contractor perform 
the work prior to any opportunity to inspect.
    (2) Except as stated in paragraph (i)(1) of this clause, and 
other than those parts furnished by the Government, and the 
Contractor shall be responsible for the correctness of the 
dimensions, sizes, and shapes of parts furnished under this 
agreement.
    (j) The Contractor shall at all times keep the site of the work 
on the vessel free from accumulation of waste material or rubbish 
caused by its employees or the work. At the completion of the work, 
unless the contract specifies otherwise, the Contractor shall remove 
all rubbish from the site of the work and leave the immediate 
vicinity of the work area ``broom clean.''

(End of clause)

1252.217-74  Subcontracts.

    As prescribed at (TAR) 48 CFR 1217.7001(b) and (c), insert the 
following clause:

Subcontracts (Oct 1994)

    (a) Nothing contained in the contract shall be construed as 
creating any contractual relationship between any subcontractor and 
the Government. The divisions or sections of the specifications are 
not intended to control the Contractor in dividing the work among 
subcontractors or to limit the work performed by any trade.
    (b) The Contractor shall be responsible to the Government for 
acts and omissions of its own employees, and of subcontractors and 
their employees. The Contractor shall also be responsible for the 
coordination of the work of the trades, subcontractors, and material 
men.
    (c) The Contractor shall, without additional expense to the 
Government, employ specialty subcontractors where required by the 
specifications.
    (d) The Government or its representatives will not undertake to 
settle any differences between the Contractor and its 
subcontractors, or between subcontractors.

(End of clause)

1252.217-75  Lay days.

    As prescribed at (TAR) 48 CFR 1217.7001(c) and (d), insert the 
following clause:

Lay Days (Oct 1994)

    (a) Lay day time will be paid by the Government at the 
Contractor's stipulated bid price for this item of the contract when 
the vessel remains on the dry dock or marine railway as a result of 
any change that involves work in addition to that required under the 
basic contract.
    (b) No lay day time shall be paid until all items of the basic 
contract for which a price was established by the Contractor and for 
which docking of the vessel was required have been satisfactorily 
completed and accepted.
    (c) Days of hauling out and floating, whatever the hour, shall 
not be paid as lay day time, and days when no work is performed by 
the Contractor shall not be paid as lay day time.
    (d) Payment of lay day time shall constitute complete 
compensation for all costs, direct and indirect, to reimburse the 
Contractor for use of dry dock or marine railway.

(End of clause)

1252.217-76  Liability and insurance.

    As prescribed at (TAR) 48 CFR 1217.7001(b) and (c), insert the 
following clause:

Liability and Insurance (Oct 1994)

    (a) The Contractor shall exercise its best efforts to prevent 
accidents, injury, or damage to all employees, persons, and 
property, in and about the work, and to the vessel or part of the 
vessel upon which work is done.
    (b) Loss or damage to the vessel, materials, or equipment. (1) 
Unless otherwise directed or approved in writing by the Contracting 
Officer, the Contractor shall not carry insurance against any form 
of loss or damage to the vessel(s) or to the materials or equipment 
to which the Government has title or which have been furnished by 
the Government for installation by the Contractor. The Government 
assumes the risks of loss of and damage to that property.
    (2) The Government does not assume any risk with respect to loss 
or damage compensated for by insurance or otherwise or resulting 
from risks with respect to which the Contractor has failed to 
maintain insurance, if available, as required or approved by the 
Contracting Officer.
    (3) The Government does not assume risk of and will not pay for 
any costs of the following:
    (i) Inspection, repair, replacement, or renewal of any defects 
in the vessel(s) or material and equipment due to--
    (A) Defective workmanship performed by the Contractor or its 
subcontractors;
    (B) Defective materials or equipment furnished by the Contractor 
or its subcontractors; or
    (C) Workmanship, materials, or equipment which do not conform to 
the requirements of the contract, whether or not the defect is 
latent or whether or not the nonconformance is the result of 
negligence.
    (ii) Loss, damage, liability, or expense caused by, resulting 
from, or incurred as a consequence of any delay or disruption, 
willful misconduct or lack of good faith by the Contractor or any of 
its representatives that have supervision or direction of--
    (A) All or substantially all of the Contractor's business; or
    (B) All or substantially all of the Contractor's operation at 
any one plant.
    (4) As to any risk that is assumed by the Government, the 
Government shall be subrogated to any claim, demand or cause of 
action against third parties that exists in favor of the Contractor. 
If required by the Contracting Officer, the Contractor shall execute 
a formal assignment or transfer of the claim, demand, or cause of 
action.
    (5) No party other than the Contractor shall have any right to 
proceed directly against the Government or join the Government as a 
codefendant in any action.
    (6) Notwithstanding the foregoing, the Contractor shall bear the 
first $5,000 of loss or damage from each occurrence or incident, the 
risk of which the Government would have assumed under the provision 
of this paragraph (b).
    (c) Indemnification. The Contractor indemnifies the Government 
and the vessel

[[Page 6526]]

and its owners against all claims, demands, or causes of action to 
which the Government, the vessel or its owner(s) might be subject as 
a result of damage or injury (including death) to the property or 
person of anyone other than the Government or its employees, or the 
vessel or its owner, arising in whole or in part from the negligence 
or other wrongful act of the Contractor, or its agents or employees, 
or any subcontractor, or its agents or employees.
    (1) The Contractor's obligation to indemnify under this 
paragraph shall not exceed the sum of $300,000 as a consequence of 
any single occurrence with respect to any one vessel.
    (2) The indemnity includes, without limitation, suits, actions, 
claims, costs, or demands of any kind, resulting from death, 
personal injury, or property damage occurring during the period of 
performance of work on the vessel or within 90 days after redelivery 
of the vessel. For any claim, etc., made after 90 days, the rights 
of the parties shall be as determined by other provisions of this 
contract and by law. The indemnity does apply to death occurring 
after 90 days where the injury was received during the period 
covered by the indemnity.
    (d) Insurance. (1) The Contractor shall, at its own expense, 
obtain and maintain the following insurance--
    (i) Casualty, accident, and liability insurance, as approved by 
the Contracting Officer, insuring the performance of its obligations 
under paragraph (c) of this clause.
    (ii) Workers Compensation Insurance (or its equivalent) covering 
the employees engaged on the work.
    (2) The Contractor shall ensure that all subcontractors engaged 
on the work obtain and maintain the insurance required in paragraph 
(d)(1) of this clause.
    (3) Upon request of the Contracting Officer, the Contractor 
shall provide evidence of the insurance required by paragraph (d) of 
this clause.
    (e) The Contractor shall not make any allowance in the contract 
price for the inclusion of any premium expense or charge for any 
reserve made on account of self-insurance for coverage against any 
risk assumed by the Government under this clause.
    (f) The Contractor shall give the Contracting Officer written 
notice as soon as practicable after the occurrence of a loss or 
damage for which the Government has assumed the risk.
    (1) The notice shall contain full details of the loss or damage.
    (2) If a claim or suit is later filed against the Contractor as 
a result of the event, the Contractor shall immediately deliver to 
the Government every demand, notice, summons, or other process 
received by the Contractor or its employees or representatives.
    (3) The Contractor shall cooperate with the Government and, upon 
request, shall assist in effecting settlements, securing and giving 
evidence, obtaining the attendance of witnesses, and in the conduct 
of suits. The Government shall reimburse the Contractor for expenses 
incurred in this effort, other than the cost of maintaining the 
Contractor's usual organization.
    (4) The Contractor shall not, except at its own expense, 
voluntarily make any payments, assume any obligation, or incur any 
expense other than what would be imperative for the protection of 
the vessel(s) at the time of the event.
    (g) In the event of loss of or damage to any vessel(s), 
material, or equipment which may result in a claim against the 
Government under the insurance provisions of this contract, the 
Contractor shall promptly notify the Contracting Officer of the loss 
or damage. The Contracting Officer may, without prejudice to any 
right of the Government, either--
    (1) Order the Contractor to proceed with replacement or repair, 
in which event the Contractor shall effect the replacement or 
repair;
    (i) The Contractor shall submit to the Contracting Officer a 
request for reimbursement of the cost of the replacement or repair 
together with whatever supporting documentation the Contracting 
Officer may reasonably require, and shall identify the request as 
being submitted under the Insurance clause of this contract.
    (ii) If the Government determines that the risk of the loss or 
damage is within the scope of the risks assumed by the Government 
under this clause, the Government will reimburse the Contractor for 
the reasonable allowable cost of the replacement or repair, plus a 
reasonable profit (if the work or replacement or repair was 
performed by the Contractor) less the deductible amount specified in 
paragraph (b) of this clause.
    (iii) Payments by the Government to the Contractor under this 
clause are outside the scope of and shall not affect the pricing 
structure of the contract, and are additional to the compensation 
otherwise payable to the Contractor under this contract; or
    (2) Decide that the loss or damage shall not be replaced or 
repaired and in that event, the Contracting Officer shall--
    (i) Modify the contract appropriately, consistent with the 
reduced requirements reflected by the unreplaced or unrepaired loss 
or damage; or
    (ii) Terminate the repair of any part or all of the vessel(s) 
under the Termination for Convenience of the Government clause of 
this contract.

(End of clause)


1252.217-77  Title.

    As prescribed at (TAR) 48 CFR 1217.7001(b) and (c), insert the 
following clause:

Title (Oct 1994)

    (a) Unless otherwise provided, title to all materials and 
equipment to be incorporated in a vessel in the performance of this 
contract shall vest in the Government upon delivery at the location 
specified for the performance of the work.
    (b) Upon completion of the contract, or with the approval of the 
Contracting Officer during performance of the contract, all 
Contractor-furnished materials and equipment not incorporated in, or 
placed on, any vessel, shall become the property of the Contractor, 
unless the Government has reimbursed the Contractor for the cost of 
the materials and equipments.
    (c) The vessel, its equipment, movable stores, cargo, or other 
ship's materials shall not be considered Government-furnished 
property.

(End of clause)


1252.217-78  Discharge of liens.

    As prescribed at (TAR) 48 CFR 1217.7001(b) and (c), insert the 
following clause:

Discharge of Liens (Oct 1994)

    (a) The Contractor shall immediately discharge or cause to be 
discharged, any lien or right in rem of any kind, other than in 
favor of the Government, that exists or arises in connection with 
work done or materials furnished under this contract.
    (b) If any such lien or right in rem is not immediately 
discharged, the Government, at the expense of the Contractor, may 
discharge, or cause to be discharged, the lien or right.

(End of clause)


1252.217-79  Delays.

    As prescribed at (TAR) 48 CFR 1217.7001(b) and (c), insert the 
following clause:

Delays (Oct 1994)

    When during the performance of this contract the Contractor is 
required to delay work on a vessel temporarily, due to orders or 
actions of the Government respecting stoppage of work to permit 
shifting the vessel, stoppage of hot work to permit bunkering, 
stoppage of work due to embarking or debarking passengers and 
loading or discharging cargo, and the Contractor is not given 
sufficient advance notice or is otherwise unable to avoid incurring 
additional costs on account thereof, an equitable adjustment shall 
be made in the price of the contract pursuant to the ``Changes'' 
clause.

(End of clause)


1252.217-80  Department of Labor Safety and Health Regulations for Ship 
Repairing.

    As prescribed at (TAR) 48 CFR 1217.7001(b) and (c), insert the 
following clause:

Department of Labor Safety and Health Regulations for Ship Repair (Apr 
2005)

    Nothing contained in this contract shall relieve the Contractor 
of any obligations it may have to comply with--
    (a) The Occupational Safety and Health Act of 1970 (29 U.S.C. 
651, et seq.);
    (b) The Occupational Safety and Health Standards for Shipyard 
Employment (29 CFR part 1915); or
    (c) Any other applicable Federal, State, and local laws, codes, 
ordinances, and regulations.

(End of clause)


1252.219-71  Section 8(a) Direct Awards.

    As prescribed in (TAR) 48 CFR 1219.811-3(f), insert the following 
clause:

[[Page 6527]]

Section 8(A) Direct Awards (Apr 2005)

    (a) This contract is issued as a direct award between the 
contracting activity and the 8(a) contractor pursuant to the 
Partnership Agreement between the Small Business Administration 
(SBA) and the Department of Transportation. SBA does retain 
responsibility for 8(a) certification, 8(a) eligibility 
determinations and related issues, and providing counseling and 
assistance to the 8(a) contractor under the 8(a) program. The 
responsible SBA district office is: [To be completed by Contracting 
Officer at time of award]
    (b) The contracting activity is responsible for administering 
the contract and taking any action on behalf of the Government under 
the terms and conditions of the contract. However, the contracting 
activity shall give advance notice to the SBA before it issues a 
final notice terminating performance, either in whole or in part, 
under the contract. The contracting activity shall also coordinate 
with SBA prior to processing any novation agreement. The contracting 
activity may assign contract administration functions to a contract 
administration office.
    (c) The contractor agrees:
    (1) To notify the Contracting Officer, simultaneous with its 
notification to SBA (as required by SBA's 8 (a) regulations), when 
the owner or owners upon whom 8(a) eligibility is based plan to 
relinquish ownership or control of the concern. Consistent with 15 
U.S.C. 637(a)(21), transfer of ownership or control shall result in 
termination of the contract for convenience, unless SBA waives the 
requirement for termination prior to the actual relinquishing of 
ownership and control.
    (2) To adhere to the requirements of 52.219-14, Limitations on 
Subcontracting.

(End of clause)


1252.219-72  Notification of Competition Limited to Eligible 8(a) 
Concerns--Alternate III.

    As prescribed in (TAR) 48 CFR 1219.811-3(d)(3), substitute the 
following paragraph for paragraph (c) of the basic FAR clause 52.219-
18, Notification of Competition Limited to Eligible 8(a) Concerns.

Notification of Competition Limited to Eligible 8(a) Concerns--
Alternate III (Apr 2005)

    (c) Any award resulting from this solicitation will be made 
directly by the Contracting Officer to the successful 8(a) offeror 
selected through the evaluation criteria set forth in this 
solicitation.

(End of clause)


1252.222-70  Strikes or picketing affecting timely completion of the 
contract work.

    As prescribed in (TAR) 48 CFR 1222.101-71(a), insert the following 
clause:

Strikes or Picketing Affecting Timely Completion of the Contract Work 
(Oct 1994)

    Notwithstanding any other provision hereof, the Contractor is 
responsible for delays arising out of labor disputes, including but 
not limited to strikes, if such strikes are reasonably avoidable. A 
delay caused by a strike or by picketing which constitutes an unfair 
labor practice is not excusable unless the Contractor takes all 
reasonable and appropriate action to end such a strike or picketing, 
such as the filing of a charge with the National Labor Relations 
Board, the use of other available Government procedures, and the use 
of private boards or organizations for the settlement of disputes.

(End of clause)


1252.222-71  Strikes or picketing affecting access to a DOT facility.

    As prescribed in (TAR) 48 CFR 1222.101-71(b), insert the following 
clause:

Strikes or Picketing Affecting Access to a DOT Facility (Oct 1994)

    If the Contracting Officer notifies the Contractor in writing 
that a strike or picketing: (a) Is directed at the Contractor or 
subcontractor or any employee of either; and (b) impedes or 
threatens to impede access by any person to a DOT facility where the 
site of the work is located, the Contractor shall take all 
appropriate action to end such strike or picketing, including, if 
necessary, the filing of a charge of unfair labor practice with the 
National Labor Relations Board or the use of other available 
judicial or administrative remedies.

(End of clause)


1252.223-70  Removal or disposal of hazardous substances--applicable 
licenses and permits.

    As prescribed in (TAR) 48 CFR 1223.303, insert the following 
clause:

Removal or Disposal of Hazardous Substances--Applicable Licenses and 
Permits (Dec 1997)

    The Contractor has ------ does not have ------ all licenses and 
permits required by Federal, state, and local laws to perform 
hazardous substance(s) removal or disposal services. If the 
Contractor does not currently possess these documents, it must 
obtain all requisite licenses and permits within ------ days after 
date of award. The Contractor shall provide evidence of said 
documents to the Contracting Officer or designated Government 
representative prior to commencement of work under the contract.

(End of clause)


1252.223-71  Accident and fire reporting.

    As prescribed in (TAR) 48 CFR 1223.7000(a), insert the following 
clause:

Accident and Fire Reporting (Apr 2005)

    (a) The Contractor shall report to the Contracting Officer any 
accident or fire occurring at the site of the work which causes:
    (1) A fatality or as much as one lost workday on the part of any 
employee of the Contractor or subcontractor at any tier;
    (2) Damage of $1,000 or more to Government-owned or leased 
property, either real or personal;
    (3) Damage of $1,000 or more to Contractor or subcontractor 
owned or leased motor vehicles or mobile equipment; or
    (4) Damage for which a contract time extension may be requested.
    (b) Accident and fire reports required by paragraph (a) above 
shall be accomplished by the following means:
    (1) Accidents or fires resulting in a death, hospitalization of 
five or more persons, or destruction of Government-owned or leased 
property (either real or personal), the total value of which is 
estimated at $100,000 or more, shall be reported immediately by 
telephone to the Contracting Officer or his/her authorized 
representative and shall be confirmed by telegram or facsimile 
transmission within 24 hours to the Contracting Officer. Such 
telegram or facsimile transmission shall state all known facts as to 
extent of injury and damage and as to cause of the accident or fire.
    (2) Other accident and fire reports required by paragraph (a) 
above may be reported by the Contractor using a state, private 
insurance carrier, or Contractor accident report form which provides 
for the statement of:
    (i) The extent of injury; and
    (ii) The damage and cause of the accident or fire.
    Such report shall be mailed or otherwise delivered to the 
Contracting Officer within 48 hours of the occurrence of the 
accident or fire.
    (c) The Contractor shall assure compliance by subcontractors at 
all tiers with the requirements of this clause.

(End of clause)


1252.223-72  Protection of human subjects.

    As prescribed in (TAR) 48 CFR 1223.7000(b), insert the following 
clause:

Protection of Human Subjects (Apr 2005)

    The Contractor shall comply with the National Highway Traffic 
Safety Administration (NHTSA) policies and procedures for the 
protection of human subjects participating in activities supported 
directly or indirectly by contracts from DOT. A copy of the 
applicable NHTSA policies and procedures shall be provided to 
offerors and/or contractors upon request. In fulfillment of its 
assurance:
    (a) A committee competent to review projects and activities that 
involve human subjects shall be established and maintained by the 
Contractor.
    (b) The committee shall be assigned responsibility to determine 
for each activity planned and conducted that:
    (1) The rights and welfare of subjects are adequately protected;
    (2) The risks to subjects are outweighed by potential benefits; 
and
    (3) The informed consent of subjects shall be obtained by 
methods that are adequate and appropriate.
    (c) Committee reviews shall be conducted with objectivity and in 
a manner to ensure the exercise of independent judgment of the 
members. Members shall be excluded from review of projects or 
activities in which they have an active role or a conflict of 
interests.

[[Page 6528]]

    (d) Continuing constructive communication between the committee 
and the project directors must be maintained as a means of 
safeguarding the rights and welfare of subjects.
    (e) Facilities and professional attention required for subjects 
who may suffer physical, psychological, or other injury as a result 
of participating in an activity shall be provided.
    (f) The committee shall maintain records of committee review of 
applications and active projects, of documentation of informed 
consent, and of other documentation that may pertain to the 
selection, participation, and protection of subjects. Detailed 
records shall be maintained of circumstances of any review that 
adversely affects the rights or welfare of the individual subjects. 
Such materials shall be made available to DOT upon request.
    (g) The retention period of such records and materials shall be 
as specified at (FAR) 48 CFR 4.703.
    (h) Periodic reviews shall be conducted by the Contractor to 
assure, through appropriate administrative overview, that the 
practices and procedures designed for the protection of the rights 
and welfare of subjects are being effectively applied.

(Note: If the Contractor has or maintains a relationship with a 
Department of Health and Human Services approved Institutional 
Review Board (IRB) which can appropriately review this contract in 
accordance with the technical requirements and applicable NHTSA 
policies and procedures, that IRB will be considered acceptable for 
the purposes of this contract).

(End of clause)


1252.223-73  Seat belt use policies and programs.

    As prescribed in (TAR) 48 CFR 1223.7000(c), insert the following 
clause:

Seat Belt Use Policies and Programs (APR 2005)

    In accordance with Executive Order 13043, Increasing Seat Belt 
Use in the United States, dated April 16, 1997, the contractor is 
encouraged to adopt and enforce on-the-job seat belt use policies 
and programs for its employees when operating company-owned, rented, 
or personally-owned vehicles. The National Highway Traffic Safety 
Administration (NHTSA) is responsible for providing leadership and 
guidance in support of this Presidential initiative. For information 
on how to implement such a program or for statistics on the 
potential benefits and cost-savings to your company or organization, 
please visit the Buckle Up America section of NHTSA's Web site at 
www.nhtsa.dot.gov. Additional resources are available from the 
Network of Employers for Traffic Safety (NETS), a public-private 
partnership headquartered in the Washington, DC metropolitan area, 
and dedicated to improving the traffic safety practices of employers 
and employees. NETS is prepared to help with technical assistance, a 
simple, user friendly program kit, and an award for achieving the 
President's goal of 90 percent seat belt use. NETS can be contacted 
at 1-888-221-0045 or visit its Web site at www.trafficsafety.org.

(End of clause)


1252.228-70  Loss of or damage to leased aircraft.

    As prescribed in (TAR) 48 CFR 1228.306-70(a) and (b), insert the 
following clause:

Loss of or Damage to Leased Aircraft (DEC 1997)

    (a) Except normal wear and tear, the Government assumes all risk 
of loss of, or damage to, the leased aircraft during the term of 
this lease while the aircraft is in the possession of the 
Government.
    (b) In the event of damage to the aircraft, the Government, at 
its option, shall make the necessary repairs with its own facilities 
or by contract, or pay the Contractor the reasonable cost of repair 
of the aircraft.
    (c) In the event the aircraft is lost or damaged beyond repair, 
the Government shall pay the Contractor a sum equal to the fair 
market value of the aircraft at the time of such loss or damage, 
which value may be specifically agreed to in clause 1252.228-71, 
``Fair Market Value of Aircraft,'' less the salvage value of the 
aircraft. However, the Government may retain the damaged aircraft or 
dispose of it as it wishes. In that event, the Contractor will be 
paid the fair market value of the aircraft as stated in the clause.
    (d) The Contractor agrees that the contract price does not 
include any cost attributable to hull insurance or to any reserve 
fund it has established to protect its interest in the aircraft. If, 
in the event of loss or damage to the leased aircraft, the 
Contractor receives compensation for such loss or damage in any form 
from any source, the amount of such compensation shall be:
    (1) Credited to the Government in determining the amount of the 
Government's liability; or
    (2) For an increment of value of the aircraft beyond the value 
for which the Government is responsible.
    (e) In the event of loss of or damage to the aircraft, the 
Government shall be subrogated to all rights of recovery by the 
Contractor against third parties for such loss or damage and the 
Contractor shall promptly assign such rights in writing to the 
Government.

(End of clause)


1252.228-71  Fair market value of aircraft.

    As prescribed in (TAR) 48 CFR 1228.306-70(a) and (c), insert the 
following clause:

Fair Market Value of Aircraft (OCT 1994)

    For purposes of the clause entitled ``Loss of or Damage to 
Leased Aircraft,'' the fair market value of the aircraft to be used 
in the performance of this contract shall be the lesser of the two 
values set out in paragraphs (a) and (b) below:
    (a) $ ------; or
    (b) If the contractor has insured the same aircraft against loss 
or destruction in connection with other operations, the amount of 
such insurance coverage on the date of the loss or damage for which 
the Government may be responsible under this contract.

(End of clause)


1252.228-72  Risk and indemnities.

    As prescribed in (TAR) 48 CFR 1228.306-70(a) and (d), insert the 
following clause:

Risk and Indemnities (DEC 1997)

    The Contractor hereby agrees to indemnify and hold harmless the 
Government, its officers and employees from and against all claims, 
demands, damages, liabilities, losses, suits and judgments 
(including all costs and expenses incident thereto) which may be 
suffered by, accrue against, be charged to or recoverable from the 
Government, its officers and employees by reason of injury to or 
death of any person other than officers, agents, or employees of the 
Government or by reason of damage to property of others of 
whatsoever kind (other than the property of the Government, its 
officers, agents or employees) arising out of the operation of the 
aircraft. In the event the Contractor holds or obtains insurance in 
support of this covenant, evidence of insurance shall be delivered 
to the Contracting Officer.

(End of clause)


1252.228-73  Notification of Miller Act payment bond protection.

    As prescribed in guidance at (TAR) 48 CFR 1228.106-470, insert the 
following clause:

Notification of Miller Act Payment Bond Protection (Apr 2005)

    This notice clause shall be inserted by first tier 
subcontractors in all their subcontracts and shall contain 
information pertaining to the surety that provided the payment bond 
under the prime contract.
    (a) The prime contract is subject to the Miller Act, (40 U.S.C. 
3131 et al), under which the prime contractor has obtained a payment 
bond. This payment bond may provide certain unpaid employees, 
suppliers, and subcontractors a right to sue the bonding surety 
under the Miller Act for amounts owed for work performed and 
materials delivery under the prime contract.
    (b) Persons believing that they have legal remedies under the 
Miller Act should consult their legal advisor regarding the proper 
steps to take to obtain these remedies. This notice clause does not 
provide any party any rights against the Federal Government, or 
create any relationship, contractual or otherwise, between the 
Federal Government and any private party.
    (c) The surety which has provided the payment bond under the 
prime contract is:
-----------------------------------------------------------------------
(Name)
-----------------------------------------------------------------------
(Street Address)
-----------------------------------------------------------------------
(City, State, Zip Code)
-----------------------------------------------------------------------
(Contact & Tel. No.)
(End of clause)

[[Page 6529]]

1252.231-70  Date of incurrence of costs.

    As prescribed in (TAR) 48 CFR 1231.205-32(b), insert the following 
clause:

Date of Incurrence of Costs (OCT 1994)

    The Contractor shall be entitled to reimbursement for costs 
incurred on or after ------------ in an amount not to exceed $------
------ that, if incurred after this contract had been entered into, 
would have been reimbursable under this contract.

(End of clause)


1252.235-70  Research misconduct.

    As prescribed in (TAR) 48 CFR 1235.7000, insert the following 
clause:

Research Misconduct (Apr 2005)

    (a) Definitions. As used in this clause--
    Adjudication means the process of reviewing recommendations from 
the investigation phase and determining appropriate corrective 
actions.
    Complainant is the person who makes an allegation of research 
misconduct or the person who cooperates with an inquiry or 
investigation.
    DOT Oversight Organization is the DOT operating administration 
or secretarial office sponsoring or managing Federally funded 
research.
    Evidence includes, but is not limited to, research records, 
transcripts, or recordings of interviews, committee correspondence, 
administrative records, grant applications and awards, manuscripts, 
publications, expert analyses, and electronic data.
    Fabrication is making up data or results and recording or 
reporting them.
    Falsification is manipulating research materials, equipment, or 
processes, or changing or omitting data or results such that the 
research is not accurately represented in the research record.
    Inquiry is preliminary information gathering and fact finding to 
determine if an allegation, or apparent instance of research 
misconduct, warrants an investigation.
    Investigation is formal collection and evaluation of information 
and facts to determine if research misconduct can be established, to 
assess its extent and consequences, and to recommend appropriate 
action.
    Plagiarism is the appropriation of another person's ideas, 
processes, results, or words without giving appropriate credit. 
Research misconduct does not include honest error or differences of 
opinion.
    Research and Technology Coordinating Council (RTCC) is the lead 
DOT entity for coordination of all actions related to allegations of 
research misconduct. The respondent in a research misconduct finding 
may appeal through the RTCC to the Deputy Secretary of 
Transportation.
    Research Institution includes any contractor conducting research 
under DOT funded contractual instruments, agreements and similar 
instruments.
    Research misconduct means fabrication, falsification, or 
plagiarism, in proposing, performing, or reviewing research, or in 
reporting research results.
    Research record is the record of data or results that embody the 
facts resulting from scientific inquiry, and includes, but is not 
limited to, research proposals, laboratory records, both physical 
and electronic, progress reports, abstracts, theses, oral 
presentations, internal reports, and journal articles.
    Respondent is the person against whom an allegation of research 
misconduct has been made, or the person whose actions are the focus 
of the inquiry or investigation.
    (b) General Guidelines. (1) Confidentiality. DOT organizations, 
including research organizations, are required to safeguard the 
confidentiality of the inquiry, investigation and decision-making 
processes, including maintaining complete confidentiality of all 
records and identities of respondents and complainants.
    (2) Retaliation prohibited. If a complainant who has reported 
possible research misconduct alleges retaliation on the part of DOT 
organization management, the report will be addressed by management 
officials who will conduct an inquiry into the allegations followed 
by an appropriate management action.
    (3) Separation of Phases. DOT organizations and research 
organizations must ensure the separation of the Inquiry, 
Investigation and Determination Phases of this process.
    (4) In general, DOT organizations must strive to protect the 
interests of the Federal Government and the public in carrying out 
this process.
    (c) Elements to support a finding of research misconduct. 
Research institutions (including contractors) that receive 
Department of Transportation (DOT) funds shall respond to 
allegations of research misconduct. The following elements describe 
the type of behavior, level of intent and burden of proof required 
to support a finding of research misconduct:
    (1) There must be a significant departure from the accepted 
practices of the relevant research community;
    (2) The misconduct must have been committed intentionally, or 
knowingly, or recklessly and;
    (3) The allegation must be proven by a preponderance of the 
evidence.
    (d) DOT Oversight Organization Investigation. The DOT oversight 
organization may proceed with its own investigation at any time if:
    (1) DOT determines the institution is not prepared to handle the 
allegation in a manner consistent with this policy;
    (2) DOT involvement is needed to protect the public interest, 
including public health and safety;
    (3) The allegation involves an entity of sufficiently small size 
(or an individual) that it cannot sufficiently conduct the 
investigation itself.
    (4) The DOT oversight organization may take, or cause to be 
taken, interim administrative actions (including special 
certifications, assurances, or other administrative actions) when 
deemed appropriate to protect the welfare of human and animal 
subjects of research, prevent inappropriate use of Federal funds, or 
otherwise protect the public interest and safety.
    (e) Investigating research misconduct. Research Institutions, or 
in limited circumstances discussed in Section b, the DOT Oversight 
Organization, shall use the following procedures to investigate 
allegations of research misconduct:
    (1) Inquire promptly into the research misconduct allegation and 
complete an initial inquiry within 60 calendar days after receipt of 
the allegation.
    (2) Notify the contracting officer immediately, in writing, when 
an inquiry results in a determination that an investigation is 
warranted, and promptly begin an investigation.
    (3) Ensure the objectivity and expertise of the individuals 
selected to review allegations and conduct investigations.
    (4) Conduct the investigation according to established internal 
procedures and complete it within 120 calendar days of completing 
the initial inquiry.
    (5) Document the investigation. Include documentation that:
    (i) Describes the allegation(s);
    (ii) Lists the investigators;
    (iii) Describes the methods and procedures used to gather 
information and evaluate the allegation(s);
    (iv) summarizes the records and data compiled, states the 
findings, and explains the supporting reasons and evidence;
    (v) states the potential impact of any research misconduct; and
    (vi) describes and explains any institutional sanctions or 
corrective actions recommended, or imposed as appropriate within its 
jurisdiction and as consistent with other relevant laws.
    (6) Provide the respondent (the person against whom an 
allegation of research misconduct has been made) with a reasonable 
opportunity (e.g., 30 calendar days) to review and respond to the 
investigation report. The respondent's written comments or rebuttal 
will be made part of the investigative record.
    (7) Within 30 calendar days after completion of an 
investigation, forward investigative reports, documentation, and 
respondent's response to the contracting officer who will coordinate 
with the oversight organization(s) sponsoring and/or monitoring the 
federally funded research.
    (8) Time extensions. Contractors should request time extensions 
as needed, from the contracting officer of the appropriate DOT 
oversight organization. The contracting officer has discretion to 
waive time requirements for good cause.
    (f) Activity sanctions or corrective actions. Upon receipt of 
the investigative reports from the contractor, the DOT oversight 
organization, in conjunction with the contracting officer, will 
review the report and determine the appropriate administrative 
action to be taken. In deciding what actions to take, the oversight 
organizations should consider: the severity of the misconduct; the 
degree to which the misconduct was knowing, intentional or reckless; 
and whether it was an isolated event or part of a pattern. Sanctions 
or corrective actions may range as follows:

[[Page 6530]]

    (1) Minimal restrictions--such as a letter of reprimand, 
additional conditions on awards, requiring third-party certification 
of accuracy or compliance with particular policies, regulations, 
guidelines, or special terms and conditions;
    (2) Moderate restrictions--such as limitations on certain 
activities or expenditures under an active award, or special reviews 
of requests for funding;
    (3) More severe restrictions--such as termination of an active 
award, or government-wide suspension or debarment.
    (i) When the DOT oversight organization concludes an 
investigation with a determination of research misconduct, the DOT 
Office of the Senior Procurement Executive may notify any other 
sources of research that provide support to the respondent that a 
finding of research misconduct has been made.
    (ii) If there are reasonable indications that criminal 
violations may have occurred, the DOT oversight organization shall 
consult with the Office of Inspector General to determine an 
appropriate course of action, including disbarment or suspension. 
The DOT oversight organization will notify the respondent in writing 
of its action, sanctions to be imposed if applicable, and the DOT 
appeal procedures.
    (g) Appeals and Final Administrative Action. (1) The Federal 
Acquisition Regulation (FAR) governs in all matters pertaining to 
termination of the contract, and suspension/debarment.
    (2) In all other cases, the contractor may appeal the sanction 
or corrective action through the DOT Research and Technology 
Coordinating Council (RTCC) to the Deputy Secretary of 
Transportation, in writing within 30 calendar days after receiving 
written notification of the research misconduct finding and 
associated administrative action(s). The contractor shall mail a 
copy of the appeal to the contracting officer.
    (3) If there is no request for appeal within 30 calendar days, 
the administrative actions of the oversight organization shall be 
final.
    (4) If a request for appeal is received by the RTCC within the 
30 calendar day limit, the Deputy Secretary may have the RTCC review 
the appeal and make recommendations.
    (5) The RTCC on behalf of the Deputy Secretary will normally 
inform the appellant of the final decision on an appeal within 60 
calendar days of receipt. This decision will then be the final DOT 
administrative action.
    (h) Criminal or Civil Fraud Violations. When the oversight 
organization concludes an investigation with a determination of 
research misconduct, the DOT Office of the Senior Procurement 
Executive may notify any other sources of research that provide 
support to the respondent. If criminal or civil fraud violations may 
have occurred, the oversight organization should promptly refer the 
matter to the DOT Inspector General, the Department of Justice or 
other appropriate investigative body.

(End of clause)


1252.236-70  Special precautions for work at operating airports.

    As prescribed in (TAR) 48 CFR 1236.570, insert the following 
clause:

Special Precautions for Work at Operating Airports (Oct 1994)

    (a) When work is to be performed at an operating airport, the 
Contractor must arrange its work schedule so as not to interfere 
with flight operations. Such operations will take precedence over 
construction convenience. Any operations of the Contractor which 
would otherwise interfere with or endanger the operations of 
aircraft shall be performed only at times and in the manner directed 
by the Contracting Officer. The Government will make every effort to 
reduce the disruption of the Contractor's operation.
    (b) Unless otherwise specified by local regulations, all areas 
in which construction operations are underway shall be marked by 
yellow flags during daylight hours and by red lights at other times. 
The red lights along the edge of the construction areas within the 
existing aprons shall be the electric type of not less than 100 
watts intensity placed and supported as required. All other 
construction markings on roads and adjacent parking lots may be 
either electric or battery type lights. These lights and flags shall 
be placed so as to outline the construction areas and the distance 
between any two flags or lights shall not be greater than 25 feet. 
The Contractor shall provide adequate watch to maintain the lights 
in working condition at all times other than daylight hours. The 
hour of beginning and the hour of ending of daylight will be 
determined by the Contracting Officer.
    (c) All equipment and material in the construction areas or when 
moved outside the construction area shall be marked with airport 
safety flags during the day and when directed by the Contracting 
Officer, with red obstruction lights at nights. All equipment 
operating on the apron, taxiway, runway, and intermediate areas 
after darkness hours shall have clearance lights in conformance with 
instructions from the Contracting Officer. No construction equipment 
shall operate within 50 feet of aircraft undergoing fuel operations. 
Open flames are not allowed on the ramp except at times authorized 
by the Contracting Officer.
    (d) Trucks and other motorized equipment entering the airport or 
construction area shall do so only over routes determined by the 
Contracting Officer. Use of runways, aprons, taxiways, or parking 
areas as truck or equipment routes will not be permitted unless 
specifically authorized for such use. Flag personnel shall be 
furnished by the Contractor at points on apron and taxiway for safe 
guidance of its equipment over these areas to assure right of way to 
aircraft. Areas and routes used during the contract must be returned 
to their original condition by the Contractor. The maximum speed 
allowed at the airport shall be established by airport management. 
Vehicles shall be operated so as to be under safe control at all 
times, weather and traffic conditions considered. Vehicles must be 
equipped with head and tail lights during the hours of darkness.

(End of clause)


1252.237-70  Qualifications of contractor employees.

    As prescribed in (TAR) 48 CFR 1237.110(a), insert the following 
clause:

Qualifications of Contractor Employees (Apr 2005)

    a. Definitions. As used in this clause--``Sensitive 
Information'' is any information that, if subject to unauthorized 
access, modification, loss, or misuse, or is proprietary data, could 
adversely affect the national interest, the conduct of Federal 
programs, or the privacy of individuals specified in The Privacy 
Act, 5 U.S.C. 552a, but has not been specifically authorized under 
criteria established by an Executive Order or an Act of Congress to 
be kept secret in the interest of national defense or foreign 
policy.
    b. Work under this contract may involve access to sensitive 
information which shall not be disclosed by the contractor unless 
authorized in writing by the contracting officer. To protect 
sensitive information, the contractor shall provide training to any 
contractor employees authorized to access sensitive information, and 
upon request of the Government, provide information as to an 
individual's suitability to have authorization.
    c. The Contracting Officer may require dismissal from work those 
employees deemed incompetent, careless, insubordinate, unsuitable, 
or otherwise objectionable, or whose continued employment is deemed 
contrary to the public interest or inconsistent with the best 
interest of national security.
    d. Contractor employees working on this contract must complete 
such forms, as may be necessary for security or other reasons, 
including the conduct of background investigations to determine 
suitability. Completed forms shall be submitted as directed by the 
Contracting Officer. Upon the Contracting Officer's request, the 
Contractor's employees shall be fingerprinted, or subject to other 
investigations as required.
    e. The Contractor shall ensure that contractor employees are:
    (1) Citizens of the United States of America or an alien who has 
been lawfully admitted for permanent residence or employment 
(indicated by immigration status) as evidenced Bureau of Citizenship 
and Immigration Services documentation; and
    (2) Have background investigations according to DOT Order 
1630.2B, Personnel Security Management.
    f. The Contractor shall immediately notify the contracting 
officer when an employee no longer requires access to DOT computer 
systems due to transfer, completion of a project retirement or 
termination of employment.
    g. The Contractor shall include the substance of this clause in 
all subcontracts at any tier where the subcontractor may have access 
to Government facilities, sensitive information, or resources.

(End of clause)


1252.237-71  Certification of data.

    As prescribed in (TAR) 48 CFR 1213.7101 and 1237.7003, insert the 
following provision:

Certification of Data (Apr 2005)

    Notice: The Secretary of Transportation has determined that this 
certification shall be

[[Page 6531]]

retained in accordance with Section 4301(b)(1)(B)(i)(II) of the 
Federal Acquisition Reform Act (Public Law 104-106, 41 U.S.C. 425, 
note) and DOT Memorandum dated July 17, 1996.

    (a) The offeror represents and certifies that to the best of its 
knowledge and belief, the information and/or data (e.g., company 
profile; qualifications; background statements; brochures) submitted 
with its offer is current, accurate, and complete as of the date of 
its offer.
    (b) The offeror understands that any inaccurate data provided to 
the Department of Transportation may subject the offeror, its 
subcontractors, its employees, or its representatives to: (1) 
prosecution for false statements pursuant to 18 U.S.C. 1001 and/or; 
(2) enforcement action for false claims or statements pursuant to 
the Program Fraud Civil Remedies Act of 1986, 31 U.S.C. 3801-3812 
and 49 CFR part 31 and/or; (3) termination for default under any 
contract resulting from its offer and/or; (4) debarment or 
suspension.
    (c) The offeror agrees to obtain a similar certification from 
its subcontractors.

Signature:-------------------------------------------------------------
Date:------------------------------------------------------------------

Typed Name and Title:

-----------------------------------------------------------------------

Company Name:----------------------------------------------------------
-----------------------------------------------------------------------

    This certification concerns a matter within the jurisdiction of 
an agency of the United States and the making of a false, 
fictitious, or fraudulent certification may render the maker subject 
to prosecution under 18 U.S.C. 1001.

(End of provision)


1252.237-72  Prohibition on advertising.

    As prescribed in (TAR) 48 CFR 1213.7101 and 1237.7003, insert the 
following clause:

Prohibition on Advertising (JAN 1996)

    The contractor or its representatives (including training 
instructors) shall not advertise or solicit business from attendees 
for private, non-Government training during contracted-for training 
sessions. This prohibition extends to unsolicited oral comments, 
distribution or sales of written materials, and/or sales of 
promotional videos or audio tapes. The contractor agrees to insert 
this clause in its subcontracts.

(End of clause)


1252.237-73  Key personnel.

    As prescribed in (TAR) 48 CFR 1237.110(b), insert the following 
clause:

Key Personnel (Apr 2005)

    (a) The personnel as specified below are considered essential to 
the work being performed under this contract and may, with the 
consent of the contracting parties, be changed from time to time 
during the course of the contract by adding or deleting personnel, 
as appropriate.
    (b) Before removing, replacing, or diverting any of the 
specified individuals, the Contractor shall notify the contracting 
officer, in writing, before the change becomes effective. The 
Contractor shall submit information to support the proposed action 
to enable the contracting officer to evaluate the potential impact 
of the change on the contract. The Contractor shall not remove or 
replace personnel under this contract until the Contracting Officer 
approves the change.
    The Key Personnel under this Contract are: (specify key 
personnel)

(End of clause)


1252.239-70  Security requirements for unclassified information 
technology resources.

    As prescribed in (TAR) 48 CFR 1239.70, insert the following clause:

Security Requirements for Unclassified Information Technology Resources 
(APR 2005)

    (a) The Contractor shall be responsible for Information 
Technology security for all systems connected to a Department of 
Transportation (DOT) network or operated by the Contractor for DOT, 
regardless of location. This clause is applicable to all or any part 
of the contract that includes information technology resources or 
services in which the Contractor has physical or electronic access 
to DOT's sensitive information that directly supports the mission of 
DOT. The term ``information technology,'' as used in this clause, 
means any equipment or interconnected system or subsystem of 
equipment, including telecommunications equipment, that is used in 
the automatic acquisition, storage, manipulation, management, 
movement, control, display, switching, interchange, transmission, or 
reception of data or information. This includes both major 
applications and general support systems as defined by OMB Circular 
A-130. Examples of tasks that require security provisions include:
    (1) Hosting of DOT e-Government sites or other IT operations;
    (2) Acquisition, transmission or analysis of data owned by DOT 
with significant replacement cost should the contractor's copy be 
corrupted; and
    (3) Access to DOT general support systems/major applications at 
a level beyond that granted the general public, e.g. bypassing a 
firewall.
    (b) The Contractor shall develop, provide, implement, and 
maintain an IT Security Plan. This plan shall describe the processes 
and procedures that will be followed to ensure appropriate security 
of IT resources that are developed, processed, or used under this 
contract. The plan shall describe those parts of the contract to 
which this clause applies. The Contractor's IT Security Plan shall 
comply with applicable Federal Laws that include, but are not 
limited to, 40 U.S.C. 11331, the Federal Information Security 
Management Act (FISMA) of 2002 and the E-Government Act of 2002. The 
plan shall meet IT security requirements in accordance with Federal 
and DOT policies and procedures, as they may be amended from time to 
time during the term of this contract that include, but are not 
limited to:
    (1) OMB Circular A-130, Management of Federal Information 
Resources, Appendix III, Security of Federal Automated Information 
Resources;
    (2) National Institute of Standards and Technology (NIST) 
Guidelines;
    (3) Departmental Information Resource Management Manual (DIRMM) 
and associated guidelines; and
    (4) DOT Order 1630.2B, Personnel Security Management
    (c) Within 30 days after contract award, the contractor shall 
submit the IT Security Plan to the DOT Contracting Officer for 
acceptance. This plan shall be consistent with and further detail 
the approach contained in the offeror's proposal or sealed bid that 
resulted in the award of this contract and in compliance with the 
requirements stated in this clause. The plan, as accepted by the 
Contracting Officer, shall be incorporated into the contract as a 
compliance document. The Contractor shall comply with the accepted 
plan.
    (d) Within 6 months after contract award, the contractor shall 
submit written proof of IT Security accreditation to the DOT for 
acceptance by the DOT Contracting Officer. Such written proof may be 
furnished either by the Contractor or by a third party. 
Accreditation must be in accordance with DOT Order 1350.2, which is 
available from the Contracting Officer upon request. This 
accreditation will include a final security plan, risk assessment, 
security test and evaluation, and disaster recovery plan/continuity 
of operations plan. This accreditation, when accepted by the 
Contracting Officer, shall be incorporated into the contract as a 
compliance document, and shall include a final security plan, a risk 
assessment, security test and evaluation, and disaster recovery/
continuity of operations plan. The contractor shall comply with the 
accepted accreditation documentation.
    (e) On an annual basis, the contractor shall submit verification 
to the Contracting Officer that the IT Security Plan remains valid.
    (f) The contractor will ensure that the following banners are 
displayed on all DOT systems (both public and private) operated by 
the contractor prior to allowing anyone access to the system:

Government Warning

**WARNING**WARNING**WARNING**

    Unauthorized access is a violation of U.S. Law and Department of 
Transportation policy, and may result in criminal or administrative 
penalties. Users shall not access other user's or system files 
without proper authority. Absence of access controls IS NOT 
authorization for access! DOT information systems and related 
equipment are intended for communication, transmission, processing 
and storage of U.S. Government information. These systems and 
equipment are subject to monitoring by law enforcement and 
authorized Department officials. Monitoring may result in the 
acquisition, recording, and analysis of all data being communicated, 
transmitted, processed or stored in this system by law enforcement 
and authorized Department officials. Use of this system constitutes 
consent to such monitoring.

**WARNING**WARNING**WARNING**

    (g) The contractor will ensure that the following banner is 
displayed on all DOT

[[Page 6532]]

systems that contain Privacy Act information operated by the 
contractor prior to allowing anyone access to the system:
    This system contains information protected under the provisions 
of the Privacy Act of 1974 (Public Law 93-579). Any privacy 
information displayed on the screen or printed shall be protected 
from unauthorized disclosure. Employees who violate privacy 
safeguards may be subject to disciplinary actions, a fine of up to 
$5,000, or both.
    (h) Contractor personnel requiring privileged access or limited 
privileged access to systems operated by the Contractor for DOT or 
interconnected to a DOT network shall be screened at an appropriate 
level in accordance with DOT Order 1630.2B, Personnel Security 
Management, as it may be amended from time to time during the term 
of this contract.
    (i) The Contractor shall ensure that its employees, in 
performance of the contract performing under this contract, receive 
annual IT security training in accordance with OMB Circular A-130, 
FISMA, and NIST requirements, as they may be amended from time to 
time during the term of this contract, with a specific emphasis on 
rules of behavior.
    (j) The Contractor shall afford the Government access to the 
Contractor's and subcontractors' facilities, installations, 
operations, documentation, databases and personnel used in 
performance of the contract. Access shall be provided to the extent 
required to carry out a program of IT inspection (to include 
vulnerability testing), investigation and audit to safeguard against 
threats and hazards to the integrity, availability and 
confidentiality of DOT data or to the function of information 
technology systems operated on behalf of DOT, and to preserve 
evidence of computer crime.
    (k) The Contractor shall incorporate the substance of this 
clause in all subcontracts that meet the conditions in paragraph (a) 
of this clause.
    (l) The contractor shall immediately notify the contracting 
officer when an employee terminates employment that has access to 
DOT information systems or data.

(End of clause)


1252.239-71  Information technology security plan and accreditation.

    As prescribed in (TAR) 48 CFR 1239.70, insert the following 
provision:

Information Technology Security Plan and Accreditation (APR 2005)

    All offers submitted in response to this solicitation must 
address the approach for completing the security plan and 
accreditation requirements in TAR clause 1252.239-70.

(End of provision)


1252.242-70  Dissemination of information--educational institutions.

    As prescribed in (TAR) 48 CFR 1242.7000(a), insert the following 
clause:

Dissemination of Information--Educational Institutions (OCT 1994)

    (a) The Department of Transportation (DOT) desires widespread 
dissemination of the results of funded transportation research. The 
Contractor, therefore, may publish (subject to the provisions of the 
``Data Rights'' and ``Patent Rights'' clauses of the contract) 
research results in professional journals, books, trade 
publications, or other appropriate media (a thesis or collection of 
theses should not be used to distribute results because 
dissemination will not be sufficiently widespread). All costs of 
publication pursuant to this clause shall be borne by the Contractor 
and shall not be charged to the Government under this or any other 
Federal contract.
    (b) Any copy of material published under this clause must 
contain acknowledgment of DOT's sponsorship of the research effort 
and a disclaimer stating that the published material represents the 
position of the author(s) and not necessarily that of DOT. Articles 
for publication or papers to be presented to professional societies 
do not require the authorization of the Contracting Officer prior to 
release. However, two copies of each article shall be transmitted to 
the Contracting Officer at least two weeks prior to release or 
publication.
    (c) Press releases concerning the results or conclusions from 
the research under this contract shall not be made or otherwise 
distributed to the public without prior written approval of the 
Contracting Officer.
    (d) Publication under the terms of this clause does not release 
the Contractor from the obligation of preparing and submitting to 
the Contracting Officer a final report containing the findings and 
results of research, as set forth in the schedule of the contract.

(End of clause)


1252.242-71  Contractor testimony.

    As prescribed in (TAR) 48 CFR 1242.7000(b), insert the following 
clause:

Contractor Testimony (OCT 1994)

    All requests for the testimony of the Contractor or its 
employees, and any intention to testify as an expert witness 
relating to: (a) Any work required by, and/or performed under, this 
contract; or (b) any information provided by any party to assist the 
Contractor in the performance of this contract, shall be immediately 
reported to the Contracting Officer. Neither the Contractor nor its 
employees shall testify on a matter related to work performed or 
information provided under this contract, either voluntarily or 
pursuant to a request, in any judicial or administrative proceeding 
unless approved, in advance, by the Contracting Officer or required 
by a judge in a final court order.

(End of clause)


1252.242-72  Dissemination of contract information.

    As prescribed in (TAR) 48 CFR 1242.7000(c), insert the following 
clause:

Dissemination of Contract Information (OCT 1994)

    The Contractor shall not publish, permit to be published, or 
distribute for public consumption, any information, oral or written, 
concerning the results or conclusions made pursuant to the 
performance of this contract, without the prior written consent of 
the Contracting Officer. Two copies of any material proposed to be 
published or distributed shall be submitted to the Contracting 
Officer.

(End of clause)


1252.242-73  Contracting officer's technical representative.

    As prescribed in (TAR) 48 CFR 1242.7000(d), insert the following 
clause:

Contracting Officer's Technical Representative (Oct 1994)

    (a) The Contracting Officer may designate Government personnel 
to act as the Contracting Officer's Technical Representative (COTR) 
to perform functions under the contract such as review and/or 
inspection and acceptance of supplies, services, including 
construction, and other functions of a technical nature. The 
Contracting Officer will provide a written notice of such 
designation to the Contractor within five working days after 
contract award or for construction, not less than five working days 
prior to giving the contractor the notice to proceed. The 
designation letter will set forth the authorities and limitations of 
the COTR under the contract.
    (b) The Contracting Officer cannot authorize the COTR or any 
other representative to sign documents (i.e., contracts, contract 
modifications, etc.) that require the signature of the Contracting 
Officer.

(End of clause)


1252.245-70  Government property reports.

    As prescribed in (TAR) 48 CFR 1245.505-70, insert the following 
clause:

Government Property Reports (Oct 1994)

    (a) The Contractor shall prepare an annual report of Government 
property in its possession and the possession of its subcontractors.
    (b) The report shall be submitted to the Contracting Officer not 
later than September 15 of each calendar year on Form DOT F 4220.43, 
Contractor Report of Government Property.

(End of clause)

Appendix to Part 1252--TAR Matrix

BILLING CODE 4910-62-P

[[Page 6533]]

[GRAPHIC] [TIFF OMITTED] TR07FE05.000


[[Page 6534]]


[GRAPHIC] [TIFF OMITTED] TR07FE05.001


[[Page 6535]]


[GRAPHIC] [TIFF OMITTED] TR07FE05.002


[[Page 6536]]



PART 1253--FORMS

Subpart 1253.2--Prescription of Forms
Sec.
1253.204 Administrative matters.
1253.222 Application of labor laws to Government acquisitions.
1253.222-70 Conveyance of invention rights acquired by the 
Government.
1253.245-70 Report of Government property.
Subpart 1253.3--Illustration of Forms 1253.303 Agency forms.

Appendix to Subpart 1253.3

Contractor's Release.
Employee Claim for Wage Restitution.
Contractor Report of Government Property.
Contractor's Assignment of Refunds, Rebates, Credits, and Other 
Amounts.
Cumulative Claim and Reconciliation Statement.

    Authority: 5 U.S.C. 301; 41 U.S.C. 418b; (FAR) 48 CFR 1.3.

Subpart 1253.2--Prescription of Forms


1253.204  Administrative matters.

    The following forms are prescribed for use in the closeout of 
applicable contracts, as specified in (TAR) 48 CFR 1204.804-570:
    (a) Form DOT F 4220.4, Contractor's Release. (See (TAR) 48 CFR 
1204.804-570.) Form DOT F 4220.4 is authorized for local reproduction 
and a copy is furnished for this purpose in the Appendix to subpart 
1253.3.
    (b) Form DOT 4220.45, Contractor's Assignment of Refunds, Rebates, 
Credits, and Other Amounts. (See (TAR) 48 CFR 1204.804-570.) Form DOT F 
4220.45 is authorized for local reproduction and a copy is furnished 
for this purpose in the Appendix to subpart 1253.3.
    (c) Form DOT F 4220.46, Cumulative Claim and Reconciliation 
Statement. (See (TAR) 48 CFR 1204.804-570.) Form DOT F 4220.46 is 
authorized for local reproduction and a copy is furnished for this 
purpose in the Appendix to subpart 1253.3.
    (d) DD Form 882, Report of Inventions and Subcontracts. (See (TAR) 
48 CFR 1204.804-570.) DD Form 882 can be found at http://www.aro.army.mil/forms/d882.pdf.


1253.222  Application of labor laws to Government acquisitions.

    The following form is prescribed for use in connection with the 
application of labor laws, as specified in (TAR) 48 CFR 1222.406-9:
    Form DOT F 4220.7, Employee Claim for Wage Restitution. (See (TAR) 
48 CFR 1222.406-9(c)(1).) Form DOT F 4220.7 is authorized for local 
reproduction and a copy is furnished for this purpose in the Appendix 
to for subpart 1253.3.


1253.227-70  Conveyance of invention rights acquired by the Government.

    The following form is prescribed as a means for contractors to 
report inventions made in the course of contract performance, as 
specified in 1227.305-4:
    DD Form 882, Report of Inventions and Subcontracts. DD Form 882 can 
be found at http://www.aro.army.mil/forms/d882.pdf.


1253.245-70  Report of Government property.

    The following form is prescribed for use by contractors to report 
Government property, as specified in (TAR) 48 CFR 1245.505-1470:
    Form DOT F 4220.43, Contractor Report of Government Property. See 
1245.505-1470.) Form DOT F 4220.43 is authorized for local reproduction 
and a copy is furnished for this purpose in the Appendix to subpart 
1253.3.

Subpart 1253.3--Illustration of Forms


1253.303  Agency forms.

    This subpart contains illustrations of DOT and other agency forms 
specified by the TAR for use in DOT acquisitions.

[[Page 6537]]

[GRAPHIC] [TIFF OMITTED] TR07FE05.003


[[Page 6538]]



Appendix to Subpart 1253.3
[GRAPHIC] [TIFF OMITTED] TR07FE05.004


[[Page 6539]]


[GRAPHIC] [TIFF OMITTED] TR07FE05.005


[[Page 6540]]


[GRAPHIC] [TIFF OMITTED] TR07FE05.006


[[Page 6541]]


[GRAPHIC] [TIFF OMITTED] TR07FE05.007


[[Page 6542]]


[GRAPHIC] [TIFF OMITTED] TR07FE05.008

[FR Doc. 05-1506 Filed 2-4-05; 8:45 am]
BILLING CODE 4910-62-C