[Code of Federal Regulations]
[Title 48, Volume 6]
[Revised as of October 1, 2007]
From the U.S. Government Printing Office via GPO Access
[CITE: 48CFR1852.212-70]

[Page 270-271]
 
            TITLE 48--FEDERAL ACQUISITION REGULATIONS SYSTEM
 
        CHAPTER 18--NATIONAL AERONAUTICS AND SPACE ADMINISTRATION
 
Sec. 1852.212-70  Notice of delay.

    As prescribed at 1812.104-70(a), insert the following clause:

                       Notice of Delay (DEC 1988)

    If, because of technical difficulties, the Contractor becomes unable 
to complete the contract work at the time specified, notwithstanding the 
exercise of good faith and diligent efforts in performing the work 
called for under this contract, the Contractor shall give the 
Contracting Officer written notice of the anticipated delay and the 
reasons for it. The notice and reasons shall be delivered promptly after 
the condition creating the anticipated delay becomes known to the 
Contractor but in no event less than 45 days before the completion date 
specified in this contract, unless otherwise permitted by the 
Contracting Officer. When notice is given, the Contracting Officer may 
extend the time specified in the Schedule for such period as is deemed 
advisable.

[[Page 271]]

                             (End of clause)